Loading...
HomeMy WebLinkAbout5953 GOODS AND SERVICES AGREEMENT THIS AGREEMENT, is entered into between the City of Bremerton, a Washington Municipal Corporation ("City"), and Hydroseeding & Barkblowers, Inc. ("Vendor"), whose mailing address is: 14021 Pioneer Way E.,Puyallup,WA 98372. The parties agree as follows: I. VENDOR SERVICES. The Vendor shall provide the following goods and materials and/or perform the following services for the City: 50 cubic yards of medium bark including blow installation for the Manette Park Improvement Project per the attached Quotation, dated March 4, 2019, attached hereto as Attachment A. II. TIME OF COMPLETION. Vendor shall complete the work and provide all goods, materials and services within 30 calendar days from the date all parties have signed this Agreement. III. COMPENSATION. The City shall pay the Vendor the total amount of $2,787.50, including applicable Washington State Sales Tax, for the goods, materials and services contemplated in this Agreement. The City shall pay the Vendor the following amounts according to the following schedule: A. Defective or Unauthorized Work. The City reserves its right to withhold payment from Vendor for any defective or unauthorized goods,materials or services. If Vendor is unable, for any reason,to complete any part of this Agreement, the City may obtain the goods, materials or services on its own or from a third party,and Vendor shall be liable to the City for any additional costs incurred by the City. "Additional costs"shall mean all reasonable costs,including legal costs and attorney fees, incurred by the City beyond the maximum Agreement price specified above. The City further reserves its right to deduct the cost to complete this Agreement, including any Additional Costs,from any and all amounts due or to become due the Vendor. IV. INDEPENDENT CONTRACTOR. Vendor is and shall be at all times acting as an independent contractor and not as an employee of the City. The Vendor shall secure at its expense, and shall be responsible for all payments of income tax, social security, state disability insurance compensation, unemployment compensation, and all other payroll deductions for the Vendor, officer, agents, employees and subcontractors. The Vendor shall also secure all applicable business licenses, if required, in connection with the contract services, including all required licenses for Vendor's officers, agents,employees and subcontractors. V. TERMINATION. The City may terminate this Agreement for good cause. "Good cause" shall include,without limitation,any one or more of the following events: A. The Vendor's refusal or failure to supply a sufficient number of properly skilled Page 1 of 8 Goods and Services Agreement Barkblowers Inc. workers or proper materials for completion of this Agreement. B. The Vendor's failure to complete this Agreement within the time specified in this Agreement. C. The Vendor's failure to make full and prompt payment to subcontractors or for material or labor. D. The Vendor's failure to comply with federal,state or local laws,rules or regulations. E. The Vendor's filing for bankruptcy or becoming adjudged bankrupt. If the City terminates this Agreement for good cause, the Vendor shall not receive any further monies due under this Agreement until the goods, materials, and services required by this Agreement are completed and fully performed by the City or a third party of the City's choosing. VI. CHANGES. The City may issue a written change order for any change in the goods, materials or services to be provided during the performance of this Agreement. If the Vendor determines,for any reason,that a change order is necessary,Vendor must submit a written change order request to an authorized agent of the City within fourteen (14) calendar days of the date Vendor knew or should have known of the facts and events giving rise to the requested change. If the City determines that the change increases or decreases the Vendor's costs or time for performance,the City will make an equitable adjustment. The City will attempt,in good faith,to reach agreement with the Vendor on all equitable adjustments. However, if the parties are unable to agree, the City will determine the equitable adjustment as it deems appropriate. The Vendor shall proceed with the change order work upon receiving either a written change order from the City or an oral order from the City before actually receiving the written change order. If the Vendor fails to require a change order within the time allowed, the Vendor waives its right to make any claim or submit subsequent change order requests for that portion of the contract work. If the Vendor disagrees with the equitable adjustment the Vendor must complete the change order work; however,the Vendor may elect to protest the adjustment as provided below: A. Procedure and Protest by the Vendor. If the Vendor disagrees with anything required by a change order, another written order, or an oral order from the City, including any direction,instruction,interpretation,or determination by the City,the Vendor shall: 1. Immediately give a signed written notice of protest to the City; 2. Supplement the written protest within fourteen (14) calendar days with a written statement that provides the following information: a. The date of the Vendor's protest. b. The nature and circumstances that caused the protest. c. The provisions in this Agreement that support the protest. d. The estimated dollar cost,if any,of the protested work and how that estimate was determined. e. An analysis of the progress schedule showing the schedule change Page 2 of 8 Goods and Services Agreement Barkblowers Inc. or disruption if the Vendor is asserting a schedule change or disruption. 2. The Vendor shall keep complete records of extra costs and time incurred as a result of the protested work. The City shall have access to any of the Vendor's records needed for evaluating the protest. The City will evaluate all protests,provided the procedures in this section are followed. If the City determines that a protest is valid,the City will adjust payment for work or time by an equitable adjustment. No adjustment will be made for an invalid protest. B. Vendor's Duty to Complete Protested Work. In spite of any protest, the Vendor shall proceed promptly to provide the goods,materials and services required by the City under this Agreement. C. Vendor's Acceptance of Changes. The Vendor accepts all requirements of a change order by: (1) endorsing it, (2)writing a separate acceptance,or(3)not protesting in the way this section provides. A change order that is accepted by Vendor as provided in this section shall constitute full payment and fmal settlement of all claims for contract time and for direct, indirect and consequential costs, including costs of delays related to any work, either covered or affected by the change. D. Failure to Protest Constitutes Waiver. By not protesting as this section provides, the Vendor also waives any additional entitlement and accepts from the City any written or oral order(including directions,instructions,interpretations, and determination). E. Failure to Follow Procedures Constitutes Waiver. By failing to follow the procedures of this section, the Vendor completely waives any claims for protested work and accepts from the City any written or oral order(including directions,instructions, interpretations, and determination). VII. CLAIMS. The Vendor shall give written notice to the City of all claims other than change orders within fourteen(14)calendar days of the occurrence of the events giving rise to the claims. Any claim for damages, additional payment for any reason, or extension of time, whether under this Agreement or otherwise, shall be conclusively deemed to have been waived by the Vendor unless a timely written claim is made in strict accordance with the applicable provisions of this Agreement; or, if(and only if) no such provision is applicable, unless that claim is set forth in detail in writing and received by the City within seven (7) calendar days from the date Vendor knew, or should have known, of the facts giving rise to the claim. At a minimum, a Vendor's written claim must include the information set forth regarding protests in Section 6(A)(2)(a)-(e). FAILURE TO PROVIDE A COMPLE 1'h, WRITTEN NOTIFICATION OF CLAIM WITHIN THE TIME ALLOWED SHALL BE AN ABSOLUTE WAIVER OF ANY CLAIMS ARISING IN ANY WAY FROM THE FACTS OR EVENTS SURROUNDING THAT CLAIM OR CAUSED BY THAT DELAY. Page 3 of 8 Goods and Services Agreement Barkblowers Inc. Vendor must,in any event, file any claim or bring any suit arising from or connected with this Agreement within 120 calendar days from the date the contract work is complete. VIII. WARRANTY. The Vendor shall correct all defects in workmanship and materials within one year from the date of the City's acceptance of the Contract work. When defects are corrected, for oneyear from the date such correction is thework shall extend o the warranty for that portion of completed and accepted by the City. The Vendor shall begin to correct any defects within seven (7) calendar days of its receipt of notice from the City of the defect. If the Vendor does not accomplish the corrections within a reasonable time, the City may complete the corrections and the Vendor shall pay all costs incurred by the City in order to accomplish the correction. IX. INDEMNIFICATION. Vendor shall defend, indemnify and hold the City, its officers, officials, employees, agents and volunteers harmless from any and all claims, injuries, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the performance of this Agreement. Vendor's obligation to indemnify shall not extend to that portion of damages caused by the City's sole negligence. The City's inspection or acceptance of any of Vendor's work when completed shall not be grounds to avoid any of these covenants of indemnification. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Vendor and the City,its officers,officials,employees,agents and volunteers,the Vendor's liability hereunder shall be only to the extent of the Vendor's negligence. IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THIS INDEMNIFICATION CONSTITUTES THE VENDOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PAR ILLS ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. The provisions of this section shall survive the expiration or termination of this Agreement. X. INSURANCE. The Vendor shall procure and maintain for the duration of this Agreement, insurance against claims for injuries to persons or damage to property that may arise from or in connection with the performance of the Contract work by the Vendor, its agents,representatives, employees or subcontractors. Before beginning work on the project described in this Agreement, the Vendor shall provide a Certificate of Insurance evidencing: A. Automobile Liability insurance with limits no less than $1,000,000 combined single limit per accident for bodily injury and property damage; and B. Commercial General Liability insurance written on an occurrence basis with Page 4 of 8 Goods and Services Agreement Barkblowers Inc. limits no less than$1,000,000 combined single limit per occurrence and$2,000,000 aggregate for personal injury,bodily injury and property damage. Coverage shall include but not be limited to: blanket contractual; products/completed operations/broad form property damage; and employer's liability. C. Excess Liability insurance with limits not less than $1,000,000 limit per occurrence and aggregate. �1 4f) D. -Professional Liabili- .. ,. - - .. ; - . :.: E. Workers Compensation insurance as statutorily required by the Industrial Insurance Act of the State of Washington, Title 51,Revised Code of Washington and employer's liability with limits not less than$1,000,000. Any payment of deductible or self-insured retention shall be the sole responsibility of the Vendor. All required policies shall be provided on an "occurrence" basis except professional liability insurance(if required),which shall be provided on a"claims-made"basis. The City shall be named as an additional insured on the Commercial General Liability insurance policy, as respects work performed by or on behalf of the Vendor and a copy of the endorsement naming the City as additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all the required insurance policies. The Vendor's Commercial General Liability insurance shall contain a clause stating that coverage shall apply separately to each insured against whom claim is made or suit is brought, except with respects to the limits of the insurer's liability. The Vendor's insurance shall be primary insurance as respects the City and shall contain a waiver o subrogation against the City for claims arising out of any operations, liabilities and obligations to which coverage applies. It shall be an affirmative obligation upon Vendor to advise the City's Risk Manager by fax at(360)473-5161,or by certified mail,return receipt requested to City of Bremerton, Attn: Risk Management, 345 6th Street, Suite 100, Bremerton, WA 98337 within two days of the cancellation, suspension or substantive change of any insurance policy set out herein, and failure to do so shall be construed to be a breach of this Agreement. The City also reserves its unqualified right to require at any time and for any reason,proof of coverage in the form of a duplicate of the insurance policy with all endorsements as evidence of coverage. XI. PREVAILING WAGES. Vendor shall file a "Statement of Intent to Pay Prevailing Wages" with the State of Washington Department of Labor and Industries prior to commencing the Contract work. Vendor shall pay prevailing wages and comply with Chapter 39.12 of the Revised Code of Washington, as well as any other applicable Page 5 of 8 Goods and Services Agreement Barkblowers Inc. prevailing wage rate provisions. The latest prevailing wage rate revision issued by the Department of Labor and Industries is attached. XII. MISCELLANEOUS. A. Licenses and Taxes. Vendor shall possess a current Bremerton Business License and any regulatory license required to fulfill Vendor's obligations under this contract. B&O taxes shall be paid when due, and Vendor, by this agreement, assigns any payments due under this contract to the City Clerk for payment of such taxes which have been declared delinquent. B. Conflict and Precedence. In the event of a conflict between the contract documents, the document which rates higher on the following list shall take precedence: 1. Addenda,if any, 2. Contract, 3. Specifications, 4. Terms and Conditions, 5. Contractor's proposal. C. Documents Incorporated by Reference. The following documents are incorporated by reference,to include,but not be limited to: 1. Terms and Conditions, 2. Specifications, 3. Proposal, and 4. Non-Collusion Affidavit. E. Use of Photographs and Images. Vendor shall not use or distribute photographs or images depicting City officials,personnel,property,or equipment whether prepared by Vendor or provided by City without prior written consent of the City. The City will not unreasonably withhold its consent. F. Nondiscrimination. In the hiring of employees for the performance of work under this Agreement the Vendor, its subcontractors,or any person acting on behalf of Vendor shall not, by reason of race, religion, color, sex, sexual orientation, national origin, or the presence of any sensory, mental, or physical disability, discriminate against any person who is qualified and available to perform the work to which the employment relates. ' G. Compliance with Laws. Vendor shall comply with all federal,state and local laws, rules and regulations throughout every aspect in the performance of this Agreement. H. Work Performed at Vendor's Risk. Vendor shall take all precautions necessary and shall be responsible for the safety of its employees, agents,and subcontractors in the performance of this Agreement. All work shall be done at Vendor's own risk, and Vendor shall be responsible for any loss of or damage to materials, tools, or other articles used or held for use in connection with the work. I. Governing Law. This Agreement shall be governed and construed in accordance Page 6 of 8 Goods and Services Agreement Barkblowers Inc. with the laws of the State of Washington.If any dispute arises between the City and Vendor under any of the provisions of this Agreement, resolution of that dispute shall be available exclusively under the jurisdiction, venue and rules of the Kitsap County Superior Court, Kitsap County, Washington. J. Attorney's Fees. In any claim or lawsuit for damages arising from the parties' performance of this Agreement,each party shall be responsible for payment of its own legal costs and attorney's fees incurred in defending or bringing such claim or lawsuit; however,nothing in this subsection shall limit the City's right to indemnification under Section 9 of this Agreement. J. Written Notice. All communications regarding this Agreement shall be sent to the parties at the addresses listed below, unless otherwise notified. Any written notice shall become effective upon delivery, but in any event three (3) calendar days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this Agreement. Notices to be sent to: Notices to be sent to: CITY: VENDOR: Attn: Jeff Elevado Attn:�c c cZ v,mrn eZ�' City of Bremerton Hydroseeding&Barkblowers,Inc. 680 Lebo Blvd. 14021 Pioneer Way E. Bremerton,WA 98310 Puyallup,WA 98372 K. Assignment. Any assignment of this Agreement by the Vendor without the written consent of the City shall be void. L. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of the City and Vendor. M. Severability. If any one or more sections, subsections, or sentences of this Agreement are held to be unconstitutional or invalid, that decision shall not affect the validity of the remaining portion of this Agreement and the remainder shall remain in full force and effect. N. Entire Agreement. The written provisions and terms of this Agreement, together with any attached Exhibits,supersede all prior verbal statements by any representative of the City, and those statements shall not be construed as forming a part of or altering in any manner this Agreement. This Agreement and any attached Exhibits contain the entire Agreement between the parties. Should any language in any Exhibit to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. IN WITNESS WHEREOF, the parties below have executed this Agreement. Page 7 of 8 Goods and Services Agreement Barkblowers Inc. CITY: VENDOR: City of Bremerton Hydroseeding&Barkblowers,Inc. By: 1 _ 4,• By s&% . Print Name: 'eff Elevado Print Name: \p t)in v11k -- Its: Director of Parks&Recreation Its: .. Date: -'S/1.3/Zolal' Date:C\`'`\ \ 1 APPROVED AS TO FORM: i ATFEST: BROy: By: GER A. OVICH, re erton Ci ttomey ANGELA DS,City Clerk R:\Legal\L.egal\Forms\FORMS ON COBWEB\Goods and Services Agreement Rev.07 2018.docx Page 8 of'8 Goods and Services Agreement Barkblowers Inc. ATTACHMENT A HYDROSEEDING & BARKBLOWERS,INC. COMMERCIAL QUOTE BARK INSTALLATION AND CLEAN UP HYDROSEEDING&BARK BLOWERS INC. JOB NAME:MINETT PARK 14021 PIONEER WAY E LOCATION: COUNTY PUYALLUP,WA 98372 NO.YARDS: 50 PHONE: 253-770-0242 ITEM BID:MEDIUM BARK,AND BLOWING FAX: 253-770-0332 DATE BID: 3/4/19 ESTIMATOR:BILL QUOTED TO: COMPANY NAME: CITY OF BREMERTON PH: . ESTIMATOR: JOHN We are pleased to quote the following machine MEDIUM BARK and blowing. Includes clean up Product blown up to 200 ft.from our truck location. Estimate of Item (1)50 PER CU YRD AT$51.75 PER CU YRD=$2587.50 MED BARK INSTALLED Lite mulch clean up limited to our machine blowing off plants sidewalks and parking lot. We have not allowed for any proportionate cost of the performance bond in these. Terms of quote thru 2019_planting season. Prices do not include any nighttime work. We have no way of getting product at night time nor can we see to install due to shadows Prevailing Wage one time only charge: Add$200.00 for paperwork. Prices are quoted at Washington Counties, Washington State prevailing wage rates. Terms of sale:N-30 days. When Use Tax on material applies the cost will be added to price above. AND OR + Washington State Sales Tax.If applicable. Terms of quote firm if accepted within 60 days of quote date,for the 2017 planting season. Any dispute must be addressed within 30 days after job completion Mobilizations have been included for 50 yards at a time with up to 1 mobs with equipment as needed to complete, each additional mobilization$NA,per mobilization per truck. Additional cost may occur if Blowers,Inc. is delayed because of owner or representative is not ready when crews arrive on job. Stand by time $195.00 per hour. Job cancelled cost if cancelled with in less than 48 hours notice $250.00. NOTE: To Customer, customer must meet at site prior to work starting to go over work to be done. CONSIDERATIONS: 1. General contractor must provide suitable access for equipment. 2. Prices subject to change if quantity is reduced 3. This is an estimate of materials required not to exceed without your consent.Billing will be based on actual yardage installed 4. CONTRACTOR,OWNER to provide all flaggers&escorts if necessary 5. OWNER responsible for notifying all tenants to close windows prior to bark blowing. 6. Owner/Customer/Landscaper responsible for having vehicles clear of work area. 7. On Commercial/Residential work you may need someone to go in behind us and fluff up ground cover THANKS FOR THE OPORTUNITY TO QUOTE. LOOK FORWARD TO YOUR VALUED BUSINESS. Bill Richardson Certification of Compliance with Wage Payment Statutes The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (3/4/2019), the bidder is not a "willful" violator, as defined in RCW 49.48.082, of any provision of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. I certify under penalty of perjury under the laws of the State of Washington that the foregoing is true and correct. Hydroseeding & Barkblowers, Inc. Bidder's Business Name Signature of Authorized Official* )4iY1 Printed Name Title Date City State Check One: Sole Proprietorship ❑ Partnership ❑ Joint Venture El Corporation pl State of Incorporation, or if not a corporation, State where business entity was formed: If a co-partnership, give firm name under which business is transacted: *If a corporation,proposal must be executed in the corporate name by the president or vice-president (or any other corporate officer accompanied by evidence of authority to sign). If a co-partnership, proposal must be executed by a partner. �® ACDATE(MM/DD/YYYY) �� CERTIFICATE OF LIABILITY INSURANCE 3/11/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Cherie Steinmetz NAME: HBT — Leavitt Group Northwest (A/C,No.Ext): (253)833-5140 FAX No): 201 Auburn Way ADDRESS:cherie—steinmetz@leavitt.com N Suite C INSURER(S)AFFORDING COVERAGE NAIC# Auburn WA 98002 INSuRERA:West American Insurance Company 44393 INSURED INSURER B:Liberty Northwest D41939 Hydroseeding, Inc. INSURER c:Ohio �C/asualty Insura a Company _A24074 dba: Hydroseeding & Barkblowers, Inc. INSURER D: O� 31 1LA- 14021 Pioneer Way E. INSURERE: `v4 N A V` . Puyallup WA 98372 INSURER F: COVERAGES CERTIFICATE NUMBER:18/19 Master REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) X COMMERCIAL GENERAL LIABILITY 4 EACH OCCURRENCE $ 1,000,000 A CLAIMS-MADE X OCCUR DAMAGETO RENTED PREMMISES(Ea occurrence) $ 100,000 X Y BKW54451455 4/24/2018 4/24/2019 MED EXP(Any one person) $ 10,000 i7 PERSONAL&ADV INJURY $ 1,000,000 GE 'L AGGREGATE LIMIT APPLIES PER: " GENERAL AGGREGATE _$ 2,000,000 POLICY X ' 1- LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: Stop Gap-Employers Liability $ 1,000,000 AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) B X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BAS54451455 4/24/2018 4/24/2019 BODILY INJURY(Per accident) $ AUTOS AUTOS HIRED AUTOS NON-OWNED PROPERTY DAMAGE $ AUTOS (Per accident) Underinsured motorist $ 1,000,000 X UMBRELLALIAB X OCCUR EACH OCCURRENCE $ / 2,000,000 C EXCESS LIAR CLAIMS-MADE 1 AGGREGATE $ �/ 2,000,000 DED RETENTION$ US054451455 4/24/2018 4/24/2019 $ WORKERS COMPENSATION PER X OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ /1,000,000 OFFICER/MEMBER EXCLUDED? N/A A (Mandatory in NH) BKW54451455 4/24/2018 4/24/2019 E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below WA Stop Gap E.L.DISEASE-POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached it more space is required) Re: Blow Installation of 50 cubic yards of medium bark for the Manette Park, County. City of Bremerton is named additional 'insured per terms and conditions of forms CG8810 0413 and CG8870 1208 attached. 4., CERTIFICATE HOLDER CANCELLATION Jeff.Elevado@ci.bremerton. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Bremerton THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Attn: Jeff Elevado ACCORDANCE WITH THE POLICY PROVISIONS. 680 Lebo Blvd. Bremerton, WA 98310 AUTHORIZED REPRESENTATIVE C Steinmetz/KRHENR �C ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD INS025(201401) COMMERCIAL GENERAL LIABILITY CG 88 10 04 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL GENERAL LIABILITY EXTENSION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART INDEX SUBJECT PAGE NON-OWNED AIRCRAFT 2 NON-OWNED WATERCRAFT 2 PROPERTY DAMAGE LIABILITY -ELEVATORS 2 EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) 2 MEDICAL PAYMENTS EXTENSION 3 EXTENSION OFASUPPLEMENTARY PAYMENTS -COVERAGES A AND B 3 ADDITIONAL II .REDS -BY CONTRACT, AGREEMENT OR PERMIT 3 PRIMARY ANDNON-CONTRIBUTORY- ADDITIONAL INSURED EXTENSION 5 ADDITIONAL INSUREDS -EXTENDED PROTECTION OF YOUR "LIMITS OF INSURANCE" 6 WHO IS AN INSURED -INCIDENTAL MEDICAL ERRORS/MALPRACTICE AND WHO IS AN INSURED - FELLOW EMPLOYEE EXTENSION -MANAGEMENT EMPLOYEES 6 NEWLY FORMED OR ADDITIONALLY ACQUIRED ENTITIES 7 FAILURE TO DISCLOSE HAZARDS AND PRIOR OCCURRENCES 7 KNOWLEDGE OF OCCURRENCE, OFFENSE, CLAIM OR SUIT 7 LIBERALIZATION CLAUSE 7 BODILY INJURY REDEFINED 7 EXTENDED PROPERTY DAMAGE 8 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - 8 WHEN REQUIRED IN A CONTRACT OR AGREEMENT WITH YOU © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 1 of 8 With respect to coverage afforded by this endorsement, the provisions of the policy apply unless modified by the endorsement. A. NON-OWNED AIRCRAFT Under Paragraph 2. Exclusions of Section I - Coverage A - Bodily Injury And Property Damage Liability, exclusion g. Aircraft, Auto Or Watercraft does not apply to an aircraft provided: 1. It is not owned by any insured; 2. It is hired, chartered or loaned with a trained paid crew; 3. The pilot in command holds a currently effective certificate, issued by the duly constituted authority of the United States of America or Canada, designating her or him a commercial or airline pilot; and 4. It is not being used to carry persons or property for a charge. However, the insurance afforded by this provision does not apply if there is available to the insured other valid and collectible insurance, whether primary, excess (other than insurance written to apply specifically in excess of this policy), contingent or on any other basis, that would also apply to the loss covered under this provision. B. NON-OWNED WATERCRAFT Under Paragraph 2. Exclusions of Section I -Coverage A-Bodily Injury And Property Damage Liability, Subparagraph (2) of exclusion g. Aircraft, Auto Or Watercraft is replaced by the following: This exclusion does not apply to: (2) A watercraft you do not own that is: (a) Less than 52 feet long; and (b) Not being used to carry persons or property for a charge. C. PROPERTY DAMAGE LIABILITY -ELEVATORS 1. Under Paragraph 2. Exclusions of Section I - Coverage A - Bodily Injury And Property Damage Liabil- ity, Subparagraphs (3), (4) and (6) of exclusion j. Damage To Property do not apply if such "property damage" results from the use of elevators. For the purpose of this provision, elevators do not include vehicle lifts. Vehicle lifts are lifts or hoists used in automobile service or repair operations. 2. The following is added to Section IV - Commercial General Liability Conditions, Condition 4. Other Insurance, Paragraph b. Excess Insurance: The insurance afforded by this provision of this endorsement is excess over any property insurance, whether primary, excess, contingent or on any other basis. D. EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) If Damage To Premises Rented To You is not otherwise excluded from this Coverage Part: 1. Under Paragraph 2. Exclusions of Section I -Coverage A-Bodily Injury and Property Damage Liability: a. The fourth from the last paragraph of exclusion j. Damage To Property is replaced by the follow- ing: Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire, lightning, explosion, smoke, or leakage from an automatic fire protection system) to: (i) Premises rented to you for a period of 7 or fewer consecutive days; or (ii) Contents that you rent or lease as part of a premises rental or lease agreement for a period of more than 7 days. Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" to contents of premises rented to you for a period of 7 or fewer consecutive days. A separate limit of insurance applies to this coverage as described in Section III - Limits of Insurance. ® 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 2 of 8 b. The last paragraph of subsection 2. Exclusions is replaced by the following: Exclusions c. through n. do not apply to damage by fire, lightning, explosion, smoke or leakage from automatic fire protection systems to premises while rented to you or temporarily occupied by you with permission of the owner. A separate limit of insurance applies to Damage To Premises Rented To You as described in Section III -Limits Of Insurance. 2. Paragraph 6. under Section III -Limits Of Insurance is replaced by the following: 6. Subject to Paragraph 5. above, the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of "property damage" to: a. Any one premise: (1) While rented to you; or (2) While rented to you or temporarily occupied by you with permission of the owner for damage by fire, lightning, explosion, smoke or leakage from automatic protection sys- tems; or b. Contents that you rent or lease as part of a premises rental or lease agreement. 3. As regards coverage provided by this provision D. EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) -Paragraph 9.a. of Definitions is replaced with the following: 9.a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning, explosion, smoke, or leakage from automatic fire protection systems to premises while rented to you or temporarily occupied by you with the permission of the owner, or for damage to contents of such premises that are included in your premises rental or lease agreement, is not an "insured contract". E. MEDICAL PAYMENTS EXTENSION If Coverage C Medical Payments is not otherwise excluded, the Medical Payments provided by this policy are amended as follows: Under Paragraph 1. Insuring Agreement of Section I - Coverage C - Medical Payments, Subparagraph (b) of Paragraph a. is replaced by the following: (b) The expenses are incurred and reported within three years of the date of the accident; and F. EXTENSION OF SUPPLEMENTARY PAYMENTS -COVERAGES A AND B 1. Under Supplementary Payments -Coverages A and B, Paragraph 1.b. is replaced by the following: b. Up to $3,000 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. 2. Paragraph 1.d. is replaced by the following: ° d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. G. ADDITIONAL INSUREDS -BY CONTRACT, AGREEMENT OR PERMIT %, 1. Paragraph 2. under Section II -Who Is An Insured is amended to include as an insured any person or organization whom you have agreed to add as an additional insured in a written contract, written agreement or permit. Such person or organization is an additional insured but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused in whole or in part by: a. Your acts or omissions, or the acts or omissions of those acting on your behalf, in the performance of your on going operations for the additional insured that are the subject of the written contract or written agreement provided that the "bodily injury" or "property damage" occurs, or the "per- sonal and advertising injury" is committed, subsequent to the signing of such written contract or written agreement; or © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 3 of 8 b. Premises or facilities rented by you or used by you; or c. The maintenance, operation or use by you of equipment rented or leased to you by such person or organization; or d. Operations performed by you or on your behalf for which the state or political subdivision has issued a permit subject to the following additional provisions: (1) This insurance does not apply to "bodily injury", "property damage", or "personal and ad- vertising injury" arising out of the operations performed for the state or political subdivision; (2) This insurance does not apply to "bodily injury" or "property damage" included within the "completed operations hazard". (3) Insurance applies to premises you own, rent, or control but only with respect to the following hazards: (a) The existence, maintenance, repair, construction, erection, or removal of advertising signs, awnings, canopies, cellar entrances, coal holes, driveways, manholes, marquees, hoist away openings, sidewalk vaults, street banners, or decorations and similar expo- sures; or (b) The construction, erection, or removal of elevators; or (c) The ownership, maintenance, or use of any elevators covered by this insurance. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insur- ance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. With respect to Paragraph 1.a. above, a person's or organization's status as an additional insured under this endorsement ends when: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or (2) That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. With respect to Paragraph 1.b. above, a person's or organization's status as an additional insured under this endorsement ends when their written contract or written agreement with you for such premises or facilities ends. With respects to Paragraph 1.c. above, this insurance does not apply to any "occurrence" which takes place after the equipment rental or lease agreement has expired or you have returned such equipment to the lessor. The insurance provided by this endorsement applies only if the written contract or written agreement is signed prior to the "bodily injury" or "property damage". We have no duty to defend an additional insured under this endorsement until we receive written notice of a "suit" by the additional insured as required in Paragraph b. of Condition 2. Duties In the Event Of Occurrence, Offense, Claim Or Suit under Section IV - Commercial General Liability Condi- tions. © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 4 of 8 2. With respect to the insurance provided by this endorsement, the following are added to Paragraph 2. Exclusions under Section I -Coverage A-Bodily Injury And Property Damage Liability: This insurance does not apply to: a. "Bodily injury" or "property damage" arising from the sole negligence of the additional insured. b. "Bodily injury" or "property damage" that occurs prior to you commencing operations at the location where such "bodily injury" or "property damage" occurs. c. "Bodily injury", "property damage" or "personal and advertising injury" arising out of the render- ing of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occur- rence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of, or the failure to render, any professional architectural, engineering or surveying services. d. "Bodily injury" or "property damage" occurring after: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or (2) That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. e. Any person or organization specifically designated as an additional insured for ongoing operations by a separate ADDITIONAL INSURED -OWNERS, LESSEES OR CONTRACTORS endorsement is- sued by us and made a part of this policy. 3. With respect to the insurance afforded to these additional insureds, the following is added to Section III -Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: a. Required by the contract or agreement; or b. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declaratio ns. H. PRIMARY AND NON-CONTRIBUTORY ADDITIONAL INSURED EXTENSION This provision applies to any person or organization who qualifies as an additional insured under any form or endorsement under this policy. Condition 4. Other Insurance of SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS is amend- ed as follows: a. The following is added to Paragraph a. Primary Insurance: If an additional insured's policy has an Other Insurance provision making its policy excess, and you have agreed in a written contract or written agreement to provide the additional insured coverage on a primary and noncontributory basis, this policy shall be primary and we will not seek contribution from the additional insured's policy for damages we cover. © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 5 of 8 b. The following is added to Paragraph b. Excess Insurance: When a written contract or written agreement, other than a premises lease, facilities rental contract or agreement, an equipment rental or lease contract or agreement, or permit issued by a state or political subdivision between you and an additional insured does not require this insurance to be primary or primary and non-contributory, this insurance is excess over any other insurance for which the addi- tional insured is designated as a Named Insured. Regardless of the written agreement between you and an additional insured, this insurance is excess over any other insurance whether primary, excess, contingent or on any other basis for which the additional insured has been added as an additional insured on other policies. I. ADDITIONAL INSUREDS -EXTENDED PROTECTION OF YOUR "LIMITS OF INSURANCE" This provision applies to any person or organization who qualifies as an additional insured under any form or endorsement under this policy. 1. The following is added to Condition 2. Duties In The Event Of Occurrence, Offense, Claim or Suit: An additional insured under this endorsement will as soon as practicable: a. Give written notice of an "occurrence" or an offense that may result in a claim or "suit" under this insurance to us; b. Tender the defense and indemnity of any claim or "suit" to all insurers whom also have insurance available to the additional insured; and c. Agree to make available any other insurance which the additional insured has for a loss we cover under this Coverage Part. d. We have no duty to defend or indemnify an additional insured under this endorsement until we receive written notice of a "suit" by the additional insured. 2. The limits of insurance applicable to the additional insured are those specified in a written contract or written agreement or the limits of insurance as stated in the Declarations of this policy and defined in Section III - Limits of Insurance of this policy, whichever are less. These limits are inclusive of and not in addition to the limits of insurance available under this policy. J. WHO IS AN INSURED -INCIDENTAL MEDICAL ERRORS/ MALPRACTICE WHO IS AN INSURED -FELLOW EMPLOYEE EXTENSION -MANAGEMENT EMPLOYEES Paragraph 2.a.(1) of Section Il -Who Is An Insured is replaced with the following: (1) "Bodily injury" or "personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), to a co-"employee" while in the course of his or her employ- ment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co-"employee" or "volunteer worker" as a consequence of Paragraph (1) (a) above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1) (a) or (b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. However, if you are not in the business of providing professional health care services or providing profes- sional health care personnel to others, or if coverage for providing professional health care ser- vices is not otherwise excluded by separate endorsement, this provision (Paragraph (d)) does not apply. Paragraphs (a) and (b) above do not apply to "bodily injury" or "personal and advertising injury" caused by an "employee" who is acting in a supervisory capacity for you. Supervisory capacity as used herein means the "employee's" job responsibilities assigned by you, includes the direct supervision of other "employ- ees" of yours. However, none of these "employees" are insureds for "bodily injury" or "personal and © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 6 of 8 advertising injury" arising out of their willful conduct, which is defined as the purposeful or willful intent to cause "bodily injury" or "personal and advertising injury", or caused in whole or in part by their intoxica- tion by liquor or controlled substances. The coverage provided by provision J. is excess over any other valid and collectable insurance available to your "employee". K. NEWLY FORMED OR ADDITIONALLY ACQUIRED ENTITIES Paragraph 3. of Section II -Who Is An Insured is replaced by the following: 3. Any organization you newly acquire or form and over which you maintain ownership or majority interest, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the expiration of the policy period in which the entity was acquired or formed by you; b. Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization; and c. Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. d. Records and descriptions of operations must be maintained by the first Named Insured. No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations or qualifies as an insured under this provision. L. FAILURE TO DISCLOSE HAZARDS AND PRIOR OCCURRENCES Under Section IV - Commercial General Liability Conditions, the following is added to Condition 6. Repre- sentations: Your failure to disclose all hazards or prior "occurrences" existing as of the inception date of the policy shall not prejudice the coverage afforded by this policy provided such failure to disclose all hazards or prior "occurrences" is not intentional. M. KNOWLEDGE OF OCCURRENCE, OFFENSE, CLAIM OR SUIT Under Section IV -Commercial General Liability Conditions, the following is added to Condition 2. Duties In The Event of Occurrence, Offense, Claim Or Suit: Knowledge of an "occurrence", offense, claim or "suit" by an agent, servant or "employee" of any insured shall not in itself constitute knowledge of the insured unless an insured listed under Paragraph 1. of Section Il -Who Is An Insured or a person who has been designated by them to receive reports of "occurrences", offenses, claims or "suits" shall have received such notice from the agent, servant or "employee". N. LIBERALIZATION CLAUSE If we revise this Commercial General Liability Extension Endorsement to provide more coverage without additional premium charge, your policy will automatically provide the coverage as of the day the revision is effective in your state. O. BODILY INJURY REDEFINED Under Section V -Definitions, Definition 3. is replaced by the following: 3. "Bodily Injury" means physical injury, sickness or disease sustained by a person. This includes mental anguish, mental injury, shock, fright or death that results from such physical injury, sick- ness or disease. 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 7 of 8 P. EXTENDED PROPERTY DAMAGE Exclusion a. of COVERAGE A. BODILY INJURY AND PROPERTY DAMAGE LIABILITY is replaced by the following: a. Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. Q. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - WHEN REQUIRED IN A CONTRACT OR AGREEMENT WITH YOU t Under Section IV - Commercial General Liability Conditions, the following is added to Condition 8. Trans- fer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have against a person or organization because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a = contract with that person or organization and included in the "products-completed operations hazard" provided: 1. You and that person or organization have agreed in writing in a contract or agreement that you waive such rights against that person or organization; and 2. The injury or damage occurs subsequent to the execution of the written contract or written agree- ment. © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 8 of 8 COMMERCIAL GENERAL LIABILITY CG 88 70 12 08 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CONSTRUCTION PROJECT(S) - GENERAL AGGREGATE LIMIT (PER PROJECT) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. For all sums which the insured becomes legally obligated to pay as damages caused by 'occurrences" under Section I - Coverage A - Bodily Injury And Property Damage Liability, and for all medical ex- penses caused by accidents under Section I - Coverage C Medical Payments, which can be attributed only to ongoing operations at a single construction project away from premises owned by or rented to you: 1. A separate Construction Project General Aggregate Limit applies to each construction project, and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations . 2. The Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products-completed operations hazard", and for medical expenses under Cov- erage C regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 3. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the Construction Project General Aggregate Limit for that construction project. Such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Construction Project General Aggregate Limit for any other construction project. 4. The limits shown in the Declarations for Each Occurrence, Fire Damage and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the applicable Construction Project General Aggregate Limit. B. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under Section I - Coverage A - Bodily Injury And Property Damage Liability, and for all medical ex- penses caused by accidents under Section I - Coverage C Medical Payments, which cannot be attrib- uted only to ongoing operations at a single construction project away from premises owned by or rented to you: 1. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the amount available under the General Aggregate Limit or the Products-Completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce any Construction Project General Aggregate Limit. C. When coverage for liability arising out of the "products-completed operations hazard" is provided, any payments for damages because of "bodily injury" or "property damage" included in the "products- completed operations hazard" will reduce the Products-Completed Operations Aggregate Limit, and not reduce the General Aggregate Limit nor the Construction Project General Aggregate Limit. D. If the applicable construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications or timetables, the project will still be deemed to be the same construction project. E. The provisions of Section III - Limits Of Insurance not otherwise modified by this endorsement shall continue to apply. CG 88 70 12 08 Includes copyrighted material of ISO Properties,Inc.,with its permission. Page 1 of 1