The URL can be used to link to this page

Home My WebLink About4544 Vendor Subject Department Status Code Amount Begin Date End Date Review Date Insurance Comments Contract Number 4544 STAN PALMER CONSTRUCTION INC Anderson Creek Wellfield Improvements Engineering CON File Class LEG 12-1 $436427.15 01/28/2006 08/31/2006 02/15/2009 GL AL E&O $2000000.00 $1000000.00 $ Insurance Total Insurance Review Date $3000000.00 07/01/2006 Pump Station 2 Upgrades Change Order #1-3/07 Vault 01/01/2009 Public Works and Utilities Department - Administration 3027 Olympus Drive. Bremerton, WA 98310 . (360) 473-2327 . FAX (360) 473-5018 June 19,2007 Travelers Casualty And Sqrety Company Of America Hartford, Connecticut 06183-9062 RE: Release of Retain age Bond for Public Works Contract Stan Palmer Construction, Inc. Retainage Bond # 1 04652096 Dear Sir or Madam: Stan Palmer Construction, Inc. has completed all work required under contract for Anderson Creek Wellfield Improvements and Pump Station No.2 Upgrade. Please release the retainage bond # 104652096 you are holding in the amount of Twenty- Two Thousand Nine Hundred Ninety-Six and 05/1 00 Dollars ($22,996.05). Thank you for your services and your prompt attention to this matter. Sincerely, J//JtI~ Mildred H. V ellegas, CPA PW & U Financial Manager enc!. cc: Stan Palmer Construction, Inc. City Clerk Contract file Ned Lever, Project Mgr '. RELEASE OF RETAINAGE BOND Bond 104652096 KNOW ALL MEN BY THESE PRESENTS, That we, Stan Palmer Construction, Inc. as Principal, and Travelers Casualty and Surety Company of America are held and firmly bound unto City ofBremerton as Surety, as Obligee, in the sum of TWENTY -TWO THOUSAND NINE HUNDRED NINETY -SIX AND 5/1 OOTHS Dollars ($ 22,996.05 ), lawfu I money of the United States of America, to the payment of which, well and truly to be paid, we bind ourselves, our heirs, executors and successors,jointIy and severally, firmly by these presents. THE CONDITION OF THE ABOVE OBLIGATION IS SUCH, That Whereas, on 01106/2006 the Principal and Obligee entered into a contract for the construction of-the Anderson Creek Wellfield Improvements, Pump Station No.2 Upgrade and; WHEREAS, the Obligee has elected to withhold from funds due or about to become due the Principal such sum (retainage) as is necessary to protect itself from claim or claims of lien unless the Principal furnishes as Surety Bond guaranteeing to hold the Obligee harmless from all loss it may suffer by reason of its releasing final retain age to the Principal. NOW, THEREFORE, if the Principal shall indemnify and hold harmless the Obligee for all loss that the Obligee may sustain by reason of release of said retainage to the Principal, then this obligation to be null and void, otherwise to remain in full force and effect. PROVIDED, HOWEVER: It is expressly understood and agreed that: I. Any suit or action hereunder must be brought within one (I) year of the date the proper court has rendered its decision on the validity and enforceability of the liens. - 2. The laws of the State of Washington of the rights and obligations of the parties hereunder. and the United States of America shall be applicable in the detennination 3. No right of action shall accrue upon or by reason hereofto, or for the use or benefit of, anyone other than the Obligee herein named. IN WITNESS WHEREOF, said Principal and Surety have hereunto set their hands and seals this 27th January ,2006 day of By: (Seal) Principal Title Travelers ~~company of America BY'~. "~. "'-~ Surety '~ Attorney-in-Fact S-336B/GEEF 10/99 {AvdAa-a;- B--, . -- AFFIDAVIT OF PUBLICATION Account # 42742 / Ad # 197732 ST ATE OF WASHINGTON COUNTY OF KITSAP I, Sarah Weller, being first duly sworn on oath, deposes and says: That she is now, and at all times embraced in the publication herein mentioned was the principal clerk of the printers and publishers of KITSAP SUN; that said newspaper has been approved as a legal newspaper by order ofthe Superior Court of the County of Kitsap, in which County it is published and is now and has been for more than six months prior to the date of the publication hereinafter referred to, published in the English language continually as a daily newspaper in Bremerton, Kitsap County, Washington, a weekly newspaper in Kitsap County, Washington and is now and during all of said time, was printed in an office maintained in the aforesaid place of publication of said newspaper; that the following is a true text of a legal advertisement as it was published in regular issues (and not in supplement form) of said newspaper on the following dates, to wit: , April 19, 2007 and that such newspaper was regularly distributed to its subscribers during all of said period. That the full amount of the fee charged for the foregoing publication is the sum of $32.56 which amount has not been paid in full. 8t~~u~ (Signature of Principal Clerk) Subscribed and sworn to before me this day of April 25, 2007 NOTICE OF COMPLETION "i:f~ ..,.'~. j. MO~,"".' ~v ~'.'. 'v~ o 0 0 ~~,?>'2,I01V t';. ~ ~ Ilt ~"'tl J:':;,.r.;O 6 0 ...... :CJ~O 01 AI,? ~~,oo 1J CI). .' /' .I 'Wif r.-.. : .of /6'\ \C; ,; <p a CJ \,-~ ~.:::::.. /' 'o7r,. . . ,,,C) 0 '" -y/,;/, .:.. ,J b .\Y.' ",0 , ,'.' . '. .. ..:::,.C'J o .J,. '^ 'A C\-\\\ T ..\..\ \,' "J' . J' ~'5'SSSS"--,-S..' . Notice of Completion has been issued to Stan Palmer Construction, on Contract No. 4544, for the Anderson Creek Well field Improvements, Pump Station 2 Upgrades project. Any parties having a claim for material, labor or damages related to this Contract have forty-five (45) days from the date of first publication of this notice to file a claim. ~ Notary Public in and for the State of Washington, Kitsap County. Paula Johnston City Clerk 345 6th Street Bremerton, Washington 98337 April 19, 2007...........................AD #20036335 Page 1 of 1 Paula Johnston From: Russell, Nora [nrussell@kitsapsun.com] Sent: Tuesday, April 17, 2007 10:00 AM To: Paula Johnston Subject: RE: Pump Station 2 Upgrades Project Hi Paula, It will publish on Thursday, April 19th. Thanks, NORA RUSSELL Kitsap Sun Phone: (360) 415-2687 Fax: (360) 792-8557 Email: NRussell@Kitsapsun.com Legals: Legals@Kitsapsun.com From: Paula Johnston [mailto:PaulaJohnston@cLbremerton.wa.us] Sent: Tuesday, April 17, 2007 9:51 AM To: Russell, Nora Cc: Ned Lever Subject: FW: Pump Station 2 Upgrades Project Hello, Nora. Please publish the attached Notice of Completion as soon as possible and send me two affidavits. Thanks. pj Paula Johnston, City Clerk City of Bremerton 345 6th Street, Suite 600, Bremerton WA 98337 360-473-5323 / 360-473-5200 fax Pau la .Johnston@ci.bremerton.wa.us From: Ned Lever Sent: Monday, April 16, 2007 11:27 AM To: Paula Johnston Subject: Pump Station 2 Upgrades Project Please advertise this in the Kitsap Sun as soon as possible. Project number 4334. Thanks Ned 4/17/2007 NOTICE OF COMPLETION Notice of Completion has been issued to Stan Palmer Construction, on Contract No. 4544, for the Anderson Creek Wellfield Improvements, Pump Station 2 Upgrades project. Any parties having a claim for material, labor or damages related to this Contract have forty-five (45) days from the date of first publication of this notice to file a claim. Paula Johnston City Clerk 345 6th Street Bremerton, Washington 98337 CITY OF BREMERTON CHANGE ORDER CONTRACT CHANGE ORDER NO: One PROJECT NAME: Anderson Creek Wellfield Improvements, Pump Station 2 Upgrades PROJECT NO: 4334 . CONTRACTOR: Stan Palmer Construction 423,500.00 DAYS: 150 ORIGINAL CONTRACT AMOUNT: PREVIOUSLY APPROVED CHANGES: 0.00 DAYS: o 12,927.15 DAYS: 36 THIS CHANGE: 436,427.15 DAYS: 186 REVISED CONTRACT AMOUNT: This Change Order covers changes to the subject contract as described herein. The Contractor shall construct, furnish equipment and materials, and perform all work as necessary or required to complete the Change Order Items. The increase or decrease in contract price shown below includes any applicable taxes. DESCRIPTION OF CHANGES INCREASE IN CONTRACT AMOUNT ($) (DECREASE) IN CONTRACT AMOUNT ($) CONTRACT TIME EXTENSION (DAYS:) o ..-- I'-- I'-- ..-- ..-- (]) ~ "S ::J 0::: 0::: X 1. Work Change Directive #1: Miscellaneous electrical 8904.47 0.00 0 improvements including replacement of the secondary service, CT can, meter base, additional conduits, and upgrades to fiber optic cable. X 2. Work Change Directive #2: Additional cost for FTS4 Control 1,789.36 0.00 0 Software. X 3. Work Change Directive #3: Contract Extension due to 0.00 0.00 36 chlorination system failure at Pump Station 2. X 4. Work Change Directive #4: 4 hours of TSI L 500.00 0.00 0 X 5. Work Change Directive #5: Extra costs associated with utility 1733.32 0.00 0 trench conflicts, and pressure gauges. NET CHANGE IN CONTRACT AMOUNT 12,927.15 0.00 36 INCREASE OR (DECREASE) Contractor acknowledges and accepts that this Change Order constitutes final settlement of all claims of any kind or nature arising from or connected with any work either covered or affected by this CONTRACT CHANGE ORDER NO: 1 PROJECT NAME: Change Order, including, without limitation, claims related to contract time, on-site or home office overhead, or lost profits. Nothing in this Change Order shall limit the City's right to bring a claim for past performance. The undersigned Contractor approves the foregoing Change Order as to the changes, if any, in the contract price specified for each item, including any and all supervision costs and other miscellaneous costs relating to the change in work, and as to the extension of time allowed, if any, for completion of the entire work due to said Change Order. This document will become a supplement of the contract and all provisions will apply hereto. It is understood that this Change Order shall be effective when approved by the City of Bremerton. The parties whose names appear below warrant that they are authorized to enter into a change order that is binding on the parties of this contract. In addition, Contractor warrants that it has or will inform the surety of this change, and shall take appropriate action to modify any bonds required under the contract to address this change. RECOMMENDED: v;7 ./ c'" PROJECrENGINEER RECOMMENDED:~~ ~ CITY ENGINEER / DIRECTOR OF PUBLIC WORKS 5/z/{7 Date 3/~/07 Date APPROVED: ACCEPTED: APPROVED AS TO FORM: fJdfl '- . / ( , i I~ v/tl Bremerton' City Attorney Page 2 of2 /o-Q ! ' CITY OF BREMERTON '1- '$ WORK CHANGE DIRECTIVE WCD#: One Page 1 Of 1 PROJECT: Pump Station 2 Project #: 4334 CONTRACTOR: Stan Palmer Construction Date: February 9, 2005 VOl J ARF nIRFr.TFn TO PRor.t=Fn PROMPTI Y wIn.... THF 1=01 I OWII\lr- rH~I\Ir-I={C::\. . - - . .. -- -.. ---. -- . - . . -- ---- . . --.... . -. ...... ...-. ---- .....- -. '~"~~\-J' 1. Puget Sound Energy has required the replacement of the existing Pump Station 2 CT enclosure, CT base, and meter socket. Provide and install the necessary equipment and conduit to upqrade these items. 2. Delete the spare 4" PVC conduit between the existing PSE power pole and the Primary power junction vault. Replace this conduit with one two inch PVC conduit between the existinq pole and the first fiber optic iunction vault. 3. Provide one additional 2 inch PVC telemetry conduit between the Well 6R transformer and the first fiber ootic iunction vault to the East. 4. Provide fiber optic cable with 6 multimode fibers instead of two multi mode fibers. 5. Replace the existinq secondary service wire between the existinq Pump Station 2 transformer and the new CT Enclosure. Provide and install 3 sets of (4) 300 KCMIL copper wire, Type XHHW-XLP-2. Use the existinq conduit. A TT ACHMENT(S): Electrical Sheet E1, Applicable submittal Sheets, Contractor's Proposal. If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order is based thereon will involve one or more of the following methods of determining the effect of the change(s). The Change Order will be executed in accordance with Section 1-04.4 of the WSDOT Standard Specifications, or Article 10 of the General Conditions. Method of determining change in Contract Price: Method of determining change in Contract Times: Unit Price D D Contractor's Records D [gJ D D Lump Sum Engineer's Records Time & Materials Other: D Other: Estimated increase (decrease) in Contract Price: Estimated increase (decrease) in Contract Times: $ 8,904.47 Substantial Completion: o days; If the change involves an increase, the estimated amount is not to be exceeded without further authorization. Ready for final payment: 0 days; If the change involves an increase, the estimated times are not to be exceeded without further authorization. RECOM~MENDED: CONTRACTOR By: AUTHORIZED: CITY OF BREMERTON By 1/~ ab, FORMS, Work Change Directive, 3-00 STAN PALMER CONSTRUCTION CHANGE ORDER PROPOSAL PROJECT: ANDERSON CREEK WELLFIELD PUMPST A TION 2 lJPGRADES TO: CITY OF BREMERTON PW &U ENGINEERING DIVISION 3027 OL YMPUS DRIVE BREMERTON,W A 98310 DESCRIPTION: Install new CT Can with new conductors change 4" pve to 2" pvc and change fiberoptic cable changes DIRECT COSTS FROM WORK SHEET 1 LABOR 2 EQUiPMENT OWNED 3 RENTAL EQUiPMENT 4 MATERIALS 5 SMALL TOOLS 6 DIRECT SUPERVISION 7 SUB TOTAL 8 SUBCONTRACTORS 9 MARK UP ON LABOR MARKUP ON MATERIALS & SERVICES MARKUP ON EQUIPMENT 10 MARK UP ON SUBCONTRACTORS Subcontractor 11 SUBTOTAL 12 WA State Sales tax (8.5% of Line 11) 13 Bonds and Insurance (1 % of lines 11 and 12) 14 Total Change Proposal Cost (not including WA State Tax, line 12) 3% 0% 29% 21% 21% 5% 8.60% 1% DATE: 5/3/2006 SPC CO NO: X-I05 0.00 direct labor w/fringes safety & insurance 0.00 Direct equipment costs 0.00 Direct rental costs 0.00 Direct material costs 0.00 3% of direct labor 0.00 0.00 Prime contractor Direct Costs, small tools & supervision 8,389.34 Subcontractor Costs DENO ELECTRIC 0.00 0.00 0.00 419.47 8,808.81 Total Prime and Subcontractors 757.56 For calculating Bonds & Insurance amount only 95.66 Bond and Insurancce on increased contract amount 8,904.47 Total Change Proposal 2".~ TELEMETRY CONDUIT (1) 4" PVC POWER CONDUIT 83ER OPTIC JUNG1l0N VAULT FOR "TElEMET (2~ 4" PVC POWER CONDUIT ~~~i'ETNL 3~Y~-6. \ (1) 4'\. PVC POWER CONDUIT COR" DRILL ADOITlONAL HOLES (1) 2" ivc TElEMETRY CONDUIT FOR CONDUIT / (1) 4" pvn POWER CONDUIT (1) 4" pve \ V \ POWER CONDUIT --1 \ ~ 1; 2" PVC Tl\EMETRY CONDUIT ENLARGED PLAN DETAIL 0\E31 . NO SCALE ~ :--.... ---- ____ -Q) 4" pve POWER CONDUIT !~{:>- WOODEDjVEGETATED AREA \ :'th'( I - 2 ,r ----- ---- ---- ---- --- - " . '':~ <l ---- I \ ~ \ '" \ " SEE ENLARGED ~ "- '-.... \ </ '~ \ "... OU.' , " -\ \ \ " ~ \ 12"01 ~\ (i) 2" PVC TELEMETRY AND CONTROLS CONJul" (1)1" PVC POWER CONDUIT (FOR FLlTURE :f,G METER) (1) 4" PVC POWER CONDUIT \ ~ " , i ~ ~ -"-(1) 2" PVC TELEMETRY CONDUIT \ r--------~ JUNCTION VAULT FOR TElEMETRY CONTROLS; CORE DRILL REQUIR ADDITONAL. HOLES FOR COND SEE DETAIL 3, E-6 - (1) I" PVC CONDUIT ...V. '. .... D~ISTING TELE 12"01 ~... . I ,:", ,,",,nO' , il/ / ~ SEt: DETAIL 2, THIS SHEET MAX, PAY WIDTH FOR EXCAVATION & BACKRLl NEAT UNE PRO\~DE ONLY. 6': CRUSHED SURFACING TOP COURSE ALONG DIRT/GRAVEL ROAD AND GRAVEL AlREA CONTINUOUS LOCATOR WIRE - 10GA COATED COPPER WIRE, (ONE FOOT ABOVE. PIPE CROWN) TYP TRENCH ZONE BACKFlLL, TYP----- SAND BEDDING CONDUIT, SEE SITE PLAN FOR TYPE AND QUANTITY 3"MIN (TYP) 3' MINIMUM CONDUIT COVER l : SPACE BE!WEEN POWER CONDUITS AND TElEMETRY CONDUITS. NO SPACE NECESSAJRY BrnVEEN TElEMETRY CONDUITS, ~p~<.€ ~~,?A.~~I~ WIU. \I S~ 6K1 Sj11...!6 UIoJ t?u t"[: ..'....'..... :r - .,. _...............:'..:. --=.e. "'-.-:<"", " ..".~.z, 7;~Xf'i:. TYPICAL TRENCH BEDDING, BACKFILL ~oN~~URFACE RESTORATION G) EXISTING TRANSFORMER GRID #611594-637357 ......-: --- (1) 4" Pve POWER CONDU~ ......-: ,..-; ~ ~ .---:::: /' .--:; : /' /' ~ SERVICE ROAD -- EDGE OF ASPHALT PAVING (TYP) ---- ---- (2) 2" PVC TELEMETRY CONDUIT (1 FOR FUTURE) (1) 4" PVC POWER CONDUIT ---- (2) 4" PVC POWER CONDUIT @ 11 4'-8" SQUARE JUNCTION VAULT, BY UTILITY VAULT 504-LA OR EQUAIL (SEE NOTE 2) 20 0 20 40 ,...,.-------... -=""'~ SCALE IN FEET SITE PLAN SCALE: 1:20 G) <&~~., GRAVEL AREA~/ ElECTRICAIL ;' CABINET, SEE: DETAIL 2, E-/4 (1) 3" PVe' POWER; CONDUIT " (2) 2" PVC TELEMETRY CONDUIT (1) 4" PVC POWER CONDUIT SAWCUT EXISTING BOTH SIDES OF TRENCH IN ASPHALT '~~~J ('} ,. >"'C CON"""~ \ (1 FOR FUTURE MAG METER POWER). SEE DETAIL 1, E6 (1) 4" PVC POWER CONDUIT CONTRAcrOR SHAlL INSTAILl ALL CABLE IN CONDUIT IN UllLITY TRENCH PER PUGET SOUND ENERGY STANDAlRDS. ~~: SHAll EXCAVATE AlREA FOR JUNCTION VAULT OF v: ALl CONDUITS 3 FEET FROM EXPECTED EDGE VAUL~TCO' .PSE REPRESENTATIVE WILL PLUM CONDUIT INTO . .... ORDINATE LOCATION WITH ENGINEER. , lOCAnON ' FRoI.4 THE OF THE TRANSFORMER IS APPROXIMATELY 95' !>ReM ffiGE OF THE ROAD. CONTRACTOR SHAILL ';:COo' DE AND INSTAll VAULT FOR TRANSFORMER, ,?"ROlI-lATE SIZE WITH PSE. ;'COo) ~ APPROXI ,:";;": .. MATE EXISTING SPOT ELEVATION. </,1>'{'"S.' Q r. Ole "',p II. )l.ot '" ~ REV!SIONS DESCRIPTION ASPHALT CLASS B 3" MINIMUM OR MATCH EXISTING. WHICHEVER IS GREATER 6' CRUSHED SURFACE TOP COURSE (2) (1) (1) 4" PVC POWER CONDUIT NOTE: TRENCH EDGE SHAlL MATCH EDGE OF PAVING ALONG SERVICE ROAD. 4" PVC POWER CONDUIT SINGLE LIFT ASPHALT PATCH CD ENLARGED PLAN DETAIL NO SCAlE CD NO SCALE o 1. 2" l I TWO INCHES AT FULL SCAlE IF NOT SCAlE ACCORDltffiL Y CITY OF BREMERTON DEPARTMENT OF PUBliC WORKS & UTILITIES ENGINEERING DIVISION WEST 580 PRESSURE ZONE IMPROVEMENTS PUMP STATION NO.2 ELECTRICAL SITE PLAN DATE BY SCALE DRAWN BY: L lAZO DATE 07/05/05 DESIGN BY: O. GOWEN CHECKED BY: J. GIBSON WASH. P.E. U DATE 07/05/05 WASH. P.E. # JJ080 DATE I1/JO/05 HORlZ. VERT. .,----- (2) 2" PVC -TELEMETRY CONDUIT .(1 IS FOR FUTURE) (1) 2" PVC TELEMETRY CONDUIT . r (1) 2" PVC TElEMETRY CONDUIT _~NDUIT (1) 4' PVC POWER CONDUIT '. _______ 15" CMP (82) ". /......-_.--.-~LE. 75.53 NEW TRANSFORMER, NOTE 3 (1) 2: PVC TELEMETRY CONDUIT (1) 4" PVC POWER CONDUIT .~ SERVICE ROAD - WELL 6R CALL TWO BUSINESS DAYS BEFORE YOU DIG 1-800-424-5555 1JRS 1501 4th A9~n(l. Ste. 1400 S~.tur:. WA. 9810j-18l1S. Telepbone {ZDa} 4.36-2700 DRAWING NO. E-1 :Z 0. STAN PALMER CONSTRUCTION CHANGE ORDER PROPOSAL PROJECT: ANDERSON CREEK WELLFIELD PUMPST A TION 2 UPGRADES TO: CITY OF BREMERTON PW &U ENGINEERING DIVISION 3027 OL YMPUS DRIVE BREMERTON, WA 98310 DESCRIPTION: Install new CT Can with new conductors change 4" PVC to 2" pvc and change fiberoptic cable changes DIRECT COSTS FROM WORK SHEET 1 LABOR 2 EQUIPMENT OWNED 3 RENTAL EQUIPMENT 4 MATERIALS 5 SMALL TOOLS 6 DIRECT SUPERVISION 7 SUB TOTAL 8 SUBCONTRACTORS 9 MARK UP ON LABOR MARKUP ON MATERIALS & SERVICES MARKUP ON EQUIPMENT 10 MARK UP ON SUBCONTRACTORS Subcontractor 11 SUBTOTAL 12 WA State Sales tax (8.5% of Line 11) 13 Bonds and Insurance (1 % of lines 11 and 12) 14 Total Change Proposal Cost (not including WA State Tax, line 12) 3% 0% 29% 21% 21% 5% 8.60% 1% DATE: 5/3/2006 SPC CO NO: X-I05 0.00 direct labor w/fiinges safety & insurance 0.00 Direct equipment costs 0.00 Direct rental costs 0.00 Direct material costs 0.00 3% of direct labor 0.00 0.00 Prime contractor Direct Costs, small tools & supervision 8,389.34 Subcontractor Costs DENO ELECTRIC 0.00 0.00 0.00 419.47 8,808.81 Total Prime and Subcontractors 757.56 For calculating Bonds & Insurance amount only 95.66 Bond and Insurancce on increased contract amount 8,904.47 Total Change Proposal ~~~ ttv (tfU"~-;::~---~.~_~~_.:===~_'-_____~._~-~=~~..~.-~:=-__~____.. loj\!OR;< ~ C( t....,,' C_/- ~~ (: //'" ..... r~~ i... ...-- t_.../'~ : r";"' ..,;' .. ~~ . .. , '." 1 ",'.. ..- -----~_.~------~-- . . ! SI~2:;, : ,\1c , ! /1 I 1'1 r-I i I 'I I ~~". " , ! J; : (f ('!f ('J 0:;, .rC)/.J~!(./ trrJI:: 2!lp!)[y ;J'I/UC Tv Xfin!~'V;i);ji._'i' I ' ^ I? "~" ! ;'.:, -,...,1 '.,"-:'" ~ "U ;....., 1 /. !.:II L'h;~t-ii~J..~ :--f " .~. ~0 ~l, '~::"'!~ i 4/ I r::!};6~R I j I I 51 I /I-ll 61 I I J I W-I ~i I I 91 , 1~!IL~,boR 111 I I I~J I /131 I , I I 11.d I I 'I I Rl 16' I .- j I II I ~h 1,91-1 120 I i , . I ~I I '221 I 'I ?3! I I' i I i i i /24 i ! f'/lATERJ.!!.-L OU.4.NTITY L.-'\50p'1_)I\II-;- ; i ! cED! I' "[ i./I.i:..T!.::RIAl... ?RIC~ iv!..L. "'-E8L.'\L EXTENSIO[\j LASOR E~:T~i\!SIOI-J .------.-J ,. f ! i r: r- .<:;) i .;) ';'J, D (' I I "..La !) .:;, vI/ I-V j -__\{ I ,-.. !Y)- ~;:; /'0 (J !f {~-~ foTliL ! i " 2~ j ~! 1 ' I 261 i 27 ! ti r ! , 1 I 29 I }-~ , ! ; ':l:() I j ~~ ; . I i 31 i : ,::.<,:! i 32 I , ^, ~ , ",;;:: ;=:; ~'; :; =::-~ --II '~I ';11 , " ~. ~ ! , , i' I'" -' <( C( LU ,- <( 2 ~) ;:i\' , .~; ~ z;: ~; -;\' ~:~ "50 ~;;, f:; 01 \: t~~1~ l ~5 r...\) ts:. '>, ::::;. .,1... "'''.. \:ti ~"....., .~!~ l:'.J. ':::: 'o" .c~ V}" c} <;;;.C\ ,r'," ~_ I'~ . i" -1-, Jj~:~ 1~ ,; (' ,~:;, ~:J, - ~.,. ~.- ,,':' ~ ;:~ ':: - ~ l~~~ I I::: J {J l\~ ':".. ''':;-' "" ~,:-i~ {,'~ t~. l - ~ ~... ""'" ~"'~ 11} , .. (, ~ 'C', '" 'E " ' , c') ." I" I ~I _.1 -.." ~ '''''' "', ..: ''-'' . ., I" ~," " I -_J ",) I c::.. '" ...... .". ~ ......,,"'t, ~~, \ : ""'....:... h""l -....J {~ :_',~:~-II=~ )j-'N =l-;~-I=;ll--;~I~;-F;: -'-~][;"-'L--;;;JI--I---;,-:' -:,;;-I=--;;- -~-I=lO C1 ,- ;';' 'I" -;;"ll,,, ;r;l-~~~\I-- ,;II~;=L-~~~ ~~)I':~ ~ll~'-'~]I~ G":'! "':' ~-I:::;~I::~;-': '--'''''11: ,', I;,; .______________ ____ _ _ ~___=__~I_=__'- ,- _-=-_~=- .... _~~~_~_~__~. ~__~_ _~__~__~~:~_.__(~~__~~"___~yJ "~."l :~:~ p \'1;;' r,~,~ !------------------ _.-- ,JOB i \,"',~C',/ l . ~ '-..-1 il I\. !-- ~~-.-2-~~,i i 31 i ! i f;;- () 1\11,l\T2RIA.L PRiCE PE!~! k;f-;:E?iAL EX-:-=.i\!S!O:\i ; I c. i , i i U\80R Uf'.!JT U\30R E~TEf\JSiCf\.! i>;;.!i, TERL!::.L OUJ~NT!lY l '1 t:<O~ ".- ........ ! , " fF g) {(if;\, ~; !U;;:) f' 6 [; /;bi) i t; () f"<- L ( ,\ /)'1(:1__' i j \-- boor i i ~~ i~ ,V?; 0..:'1'! + L(I'-, heir , , i 27 i , , I 28 l J j I i I 29 : r_L. 13G i ! 32 133 ; -. - ."- : C';~:;; : ;-.:;;' ;::.~.S,:;~ . ~-S:;-::;':,~;-( ;::~..: .' ~ : /~ JGB !," " \t\/ORJ-( c~/( ... ~~,eo,s ~ -=i IJ! i' t I I I ! i o i ([. i 31 I ! i i t I I UJ I 81 i m ~ 111 I I 1~'ln ....' h-" ~I 111.111' I . I t I "1 115 i c~ l:! I 117 I " 18 i I I 119 i I /20 I I ~! I 1221 I '1 : I . 23 i I Ii! L:l! 1251 I , I , 125 I . 1 , i "i ,-, 5! I " ! O! l;::< t:Y/I-~!f , I ! c,. f ( t""',J - ~~~~O '\ 0~ f) ~f ot ~7/ LV-. \0 0 r Tb~u'- [ ! 27l I I I ' , , i 23; i r-+-; 1 291 I ! , ' ! i ! I 30 I ! ! I t I i I 31 i i ! ! .'32 i . I 1 34 ! '. 'h" ,_ .._' ~. ,.~: "_' .;:;; .;;:", ,'--, U\30R E~~-I-E)',jSiCH <- :"":';:, k t .' // ,,// -------~--~--_._--_._-------_._-_._-'- --.-----.--- , ' - ,'''i i 0'....,:.:; i . .. ~ _y r_ ._---------=---~_.- \/'. C'i-=:~< , ' ----------~-_.._------------~-~-- ' ivl.'\TEi=iIAL QUANT!T':' ." j I L",2C~R Uf\i:T ; C~i=1; LA3C'R EXT:=NSICN rr-;! I III n-I ! 'i ! ('t 11 1& F,bQ~:, L1-1~0,.LJ i L ii' I 4 I I 5 i i I I 1-'[' I 6, I t~X(NffJ("'~ Gl! ' 11l 7-0 The L. ~ 1,1 I 'I' I~- I I ' 13 I I 1'4\ I 1,51 I I , ' I 161 I 17H- 01 1'91l 120 I I r-' , I 21 I ! ~i I ,i i I 23 i I , L-L- 1-; I 1241 I r 1 I 125 I j I , 126! I :....-.-.:- :. ';'l,.." (. f~ "ft: t ~n Tf-.~t{(tt~'I~J.:j t" ..._~ "-~-". ;- ,;,7' 1"-"- lA-d.;:~ L_ " *:,< i: !vIi) 0"",,,, J::; ~J' ~"" /1 ~,,:!:)r ;J IC) /:~ c" f rt1JI'S Boy, ; ; I 2~ I I ! 11 I 28 ! ; 1 I , i 29 ! i 30 I ! ] "131 ! : , ! 32 ! ! 33 i j ''';- ; -; :::::~::~ : i;iS :;;r,B-::: : ;".:;:;-:;;;.::;; ;":,;-,:.:: T.J F~<'s,.-:;;;,::; i::">f-;/ :~T~,~.' ::-------'~~~~~ .. ; . ' , ' , , , ' , . , , , ' ----~---~.~. Fiber Network Interface (FNI) 1-12 Fibers Description The Fiber Network Interface provides an optical demarcation point for Fiber-to-the-x applications. Mounted on the inside or outside of the structUre, the optical NID provides physical protection for the transition benveen provider and customer, and facilitates system testing. Note: Cabling is not included in units. Features I Benefits · Designed for FITx applications · Housings for 1 to 12 fibers · Maintains proper bend radii · Manages fiber slack · Integrated strain-relief · Lockable (with service provider override) · Molded of engineering-grade thermoplastic that is both flame-retardant and impact-resistant. · Snap-tight cover ensures weather-resistant seal · Indoor and outdoor " !l, I C~.'.~~... Corning Ca ble Systems ,-6 Fiber Housing I photo 8825 2-12 Fiber Housing I photo FOHo, Product Specifications Fiber Network Interface (FN I) 1-12 Fibers Corning Cable Systems Specifications Housing 76 Adapters - Ceramic Sleeves No Splice Capabilities 1 - 6 Fiber Interconnections 1 SC Simplex 1 - 3 SC Duplex 1 - 6 ST" compatible Simplex Fusion Splice Capable 2 - 12 Fiber Interconnections 1 - 6 SC Duplex Outside Dimensions- (H x W x D) in 10.2 x 8.5 x 3.0 Strain-Relief Cable Ties 79 14.2 x 13.5 x 4.0 Cable Clamp on Drop Cable Ties on Outgoing Ordering Information -,9 "Co ~ FNI-Qg- 000- 0 II gOD II Select housing. (number of fiber inputs, number of adapters) 76 = CDP0807 /7600 (1 - 6 Fiber: 1 SC Simplex, 1 - 3 SC Duplex, or 1 - 6 ST compatible Simplex Adapters) 79 = CDPI211 / 7900 (2 - 12 Fiber: 1 - 6 SC Duplex Adapters) r; Select fan-out kit. A = 6 Line B = 12 Line (*Standard on 79 housing) U = Not Equipped l!J Select number of adapters. 11 - 6 (* See Housing Options in D) ~ Select number of splice trays. 1 - 6 (* Available only with 79 housing) U = Not Equipped Select type of fiber adapter. A APC, SC, SM, Duplex B = SC, SM, Duplex ./-:--- C = SC, MM, Duplex.oc;; D = ST compatible, SM, Simplex (*76 housing only) E SC, SM, Simplex (*76 housing only) F = SC, MM, Simplex (*76 housing only) i; I C~.!.~~.~. ~ Corning Cable Systems LLC . PO Box 489' Hickory, NC ,8603-0489 USA 1-800-743-267S. FAX:828-901-5973 . International: 828~01-5ooo' http://www.coming.com/cabl.'y,tems Corning Cable Systems reserves the right to improve, enhance, and modify the features and specifications afeaming Cable Systems' products without prior notification. ST is a registered trademark of Lucent Technologies. All other trademarks are the properties of their respective OY/ners. Corning Cable Systems is ISO 9001 certjfied. ()2002 Corning Cable Systems. All rights reserved_ Published in the USA. TfL269B.EN / February 2002/2_SM CITY OF BREMERTON WORK CHANGE DIRECTIVE WGD#: Two Page 1 Of 1 PROJECT: Pump Station 2 Project #: 4334 CONTRACTOR: Stan Palmer Construction Date: June 30, 2006 Vf"Ill AD!:' nID!:'f'T!:'n Tf"I DDf"If'!:'!:'n DDf"IJI./IDTI v '^lITU TU!:' l:f"Il I f"I'^lI~J~ f'UAt.J~!:'/C:'. . ""..., ,"",I"'~ ....(1'\.1-.'-' I L..L.I . '" . .,"''''1-........ I .'''-'1'11 . L.. I .WI.. I I IlL.. 1"'__"'......"'" "'. ,,"'u''-''I-.'''''J- 1. To maintain and program PS2, and future control systems, FTS4Control software is required. Please provide Protocol Analyizer - By Frontline Test Equipment. Approximate cost - $3;598. This exceeds the $2000 Spare parts allowance identified in Section 170003.5 by $1012. A TT ACHMENT(S): If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order is based thereon will involve one or more of the following methods of determining the effect of the change(s). The Change Order will be executed in accordance with Section 1-04.4 of the WSDOT Standard Specifications, or Article 10 of the General Conditions. Method of determining change in Contract Price: Method of determining change in Contract Times: o ~ D D Unit Price D D Contractor's Records Lump Sum Engineer's Records Time & Materials Other: D Other: Estimated increase (decrease) in Contract Price: Estimated increase (decrease) in Contract Times: $ 1,789.76 Substantial Completion: o days; If the change involves an increase, the estimated amount is not to be exceeded without further authorization. Ready for final payment: 0 days; If the change involves an increase, the estimated times are not to be exceeded without further authorization. RECOMMENDED: CONT~ ~ BY:~ AUTHORIZED: CITY OF BREMERTON ~~/ I / By: V/?/ ( I ; ! ~ /2-/0? ab, FORMS, Work Change Directive, 3-00 03/05/2007 13:10 350-574-7190 STAN PALMER OONST PAGE 02/02 CITY OF BREMERTON WORK CHANGE DIRECTIVE PROJECT: Pump Station 2 Page 1 Of 1 Project #: 4334 WCD#: Three CONTRACTOR: Stan Palmer Construction Date: August 14, 2006 YOU ARE DIRECTED TO PROCEED PROMPTLY WITH THE FOLLOWING CHANGE(S): 1. Extend the contract time for Substantial Completion to Tuesday, August 23. 2006 due to delays caused by the chlorination system faiiure at Pump Station 2. ATTACHMENT(S): If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order is based thereon will involve one or more of the following methods of determining the effect of the change(s)_ The Change Order will be exec'....ted in accordance with Section 1"()4.4 of the WSDOT Standard Specffications, or Article 10 of the General Conditions. 0 Unit Price 0 Lump Sum 0 Time & Materials 0 Other: Method of determining change in Contract Times: o Contractor's Records o Engineer's Records Method of determining change in Contract Price: o Other: Estimated increase (decrease) in Contract Price: Estimated increase (decrease) in Contract TImes: $0.00 Substantial Completion: 36 days; If the change involves an increase, the estimated amount is not to be exceeded without further authorization. Ready for final payment: 36 days; If the change Involves an increase, the estimated times are not to be exceeded without further authorization. AUTHORIZED: CITY OF BREMERTON By: /( 3/2 6) ab, FORMS. Wort" CI'la~ OirneliVe, 3-00 CITY OF BREMERTON WORK CHANGE DIRECTIVE WCD#: Four Page 1 Of 1 PROJECT: Pump Station 2 Project #: 4334 CONTRACTOR: Stan Palmer Construction Date: October 2,2006 YOU ARE D!RECTED TO PROCEED PROMPTLY W!TH THE FOLLOW!NG CHANGE(S): 1. The City will compensate SPC for 4 hours of TSllabor which is required to install the current transformers in the Pump Station 2 VFD enclosures for the 120 V fans. - ATTACHMENT(S): If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order is based thereon will involve one or more of the following methods of determining the effect of the change(s). The Change Order will be executed in accordance with Section 1-04.4 of the WSDOT Standard Specifications, or Article 10 of the General Conditions. Method of determining change in Contract Price: Method of determining change in Contract Times: Lump Sum D D Contractor's Records D ~ D D Unit Price Engineer's Records Time & Materials Other: D Other: Estimated increase (decrease) in Contract Price: Estimated increase (decrease) in Contract Times: $ 500.00 Substantial Completion: o days; If the change involves an increase, the estimated amount is not to be exceeded without further authorization. Ready for final payment: 0 days; If the change involves an increase, the estimated times are not to be exceeded without further authorization. AUTHORIZED: CITY OF BREMERTON By: By: f/. / L-. :3h107 I I ab, FORMS, Work Change Directive, 3-00 CITY OF BREMERTON WORK CHANGE DIRECTIVE VVCD#: Five Page 1 Of 1 PROJECT: Pump Station 2 Project #: 4334 CONTRACTOR: Stan Palmer Construction Date: February 27, 2007 YOU ARE DIRECTED TO PROCEED PROMPTLY WITH THE FOllOWING CHANGE(S): 1. Extra costs associated with utility trench conflicts, and pressure gauges. ATTACHMENT(S): Contractor Costs If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order is based thereon will involve one or more of the following methods of determining the effect of the change(s). The Change Order will be executed in accordance with Section 1-04.4 of the WSDOT Standard Specifications, or Article 10 of the General Conditions. Method of determining change in Contract Price: Method of determining change in Contract Times: Unit Price o o Contractor's Records o o ~ o Lump Sum Engineer's Records Time & Materials Other: o Other: Estimated increase (decrease) in Contract Price: Estimated increase (decrease) in Contract Times: $ 1,733.32 Substantial Completion: o days; If the change involves an increase, the estimated amount is not to be exceeded without further authorization. Ready for final payment: 0 days; If the change involves an increase, the estimated times are not to be exceeded without further authorization. RECOMMENDED: CONT~ By: / +- /o/%-~ 1 AUTHORIZED: CITY OF BREMERTON ~1 / L-- S/z~7 ( . I By: ab, FORMS, Work Change Directive, 3-00 STAN PALMER CONSTRUCTION CHANGEO~DERPROPOSAL PROJECT: ANDERSON CREEK PUMP STATION DATE: 10/2/2006 TO: CITY OF BREMERTON PW 3027 OL YMPUS DRIVE BREMERTON, WA 98310 SPCCONO: X-01 DESCRIPTION: REPAIR WATER SERVICE DIRECT COSTS FROM WORK SHEET 1 LABOR 66.07 direct labor w/fringes safety & insurance 2 EQUIPMENT OWNED 0.00 Direct equipment costs 3 RENTAL EQUIPMENT 0.00 Direct rental costs 4 MATERIALS 46.50 Direct material costs 5 SMALL TOOLS 3% 1.98 3% of direct labor 6 DIRECT SUPERVISION 0% 0.00 7 SUB TOTAL 114.56 Prime contractor Direct Costs, small tools & supervision 8 SUBCONTRACTORS 0.00 Subcontractor Costs 9 MARK UP ON LABOR 29% 19.16 MARKUP ON MATERIALS & SERVICES 21% 9.77 MARKUP ON EQUIPMENT 21% 0.00 10 MARK UP ON SUBCONTRACTORS 12% 0.00 Su bcontractor 11 SUBTOTAL 143.48 Total Prime and Subcontractors 12 WA State Sales tax (8.5% of Line 11) 8.60% 12.34 F or calculating Bonds & Insurance amount only 13 Bonds and Insurance (1 % of lines 11 and 12) 1% 1.56 Bond and Insurancce on increased contract amount 14 Total Change Proposal Cost 145.04 Total Change Proposal (not including WA State Tax, line 12) <I~ H.D. FOWLER COMPANY PO ~Rf 180' BeIlevue, WA . 98009-0160 N~~~~~ r1821162 Bellevue Bellingham Bend Bremerton Clackamas Eugene Hayden Hillsboro BRWH # 162410 To: 425.746.8400 360.734,8400 541.389.7577 360.377-4507 503.656.3900 541-607.0081 208.772-9060 503.626.2466 Ship to: PO BOX 2057 11,1"I..I".III1I1I1I",II.! .1.11,11,.1,,11111'111.1.1.11..,1 3 STAN PALMER CONSTRUCTION 5107 STATE HIGHWAY 3 SW PORT ORCHARD WA 98367-7486 ? Order#: ..02196932 03/10/06 W ILL CALL PO/JOB: CHEMICAL PLANT tOol \-~t Teims: . Due: FOB: H. D. FOW LER Ship Via: ~ """"11' Jr-r-"\r""lo. A I r- .::> IL v t:.,",UAU:: Inv Date: 02/16/06 Marysville Olympia Pacific Pasco Redmond Spokane Wenatchee Yakima 360.651.2400 360.459.7300 253.863.8600 509.545.0255 541.923.2090 509.568.8400 509.886.8804 509~8'8400 Order Writer: 'vV A 983832057 DONALD SCOTT Qty Qty Part # Unit Extended T Ship'd BO'd UoM Description Price Price X 4 0 EA 3/4" FORD CTS STIFFENER FORD #51 0.940 3.76 100 0 FT 3/4" SOR 9 200 PSI POLY TUBING, PE 3408, ASTM 0.240 24.00 02239, COPPER SIZE, 100FT. COIL Line 2 3 KEVIN Serving the Pacific Northwest since 1911 Sub Total Freight Tax Grand Total 42.52 0.00 0.00 42.52 ~ H.D. FOWLER COMPANY p~:~~ - BeIle~~rf~ -f8j9bi 0 To: 3 1I.1..I..I...IIIIIiIlI'llll 11.1.1..11..1111111111.1.1.1.1111.1 STAi~ PALiviER COi'-JSTRUCTiON 5107 STATE HIGHWAY 3 SW PORT ORCHARD WA 98367-7486 KEVIN BRWH # 162410 Bellevue 425.746.8400 Bellingham 360.734.8400 Olympia Bend 541.389.7577 Pacific Bremerton 360.377.4507 Pasco Clackamas 503.656.3900 Redmond Eugene 541-607 .0081 Spokane Hillsboro 503.626.2466 Wenatchee Marysville 360.651.2400 Yakima Ship to:PO BOX 2057 QII \II=DI\^' C "'-..,IlL- v L-I '\.LJr-\L-L- 360.459.7300 253.863-8600 509.545.0255 541.923- 2090 509.568.8400 509.886.8804 50@,248.8400 nter: 1M ^ OQ':)Q'Y)/lt::7 v Y 1\ .:JVvUo.JLV0 I Inv Date: !~ ~ ~ ~., 02/01/06 L1NARD KINARD Terms: FOB: H. D. FOW LER Ship Via: W ILL CALL !l.ll Qty Qty Part # Line Ship'd BO'd UoM Description ( e;lt Unit Price xtended T Price X Sub Total Freight Tax Grand Total Serving Ute Pacific NorU1west since 1935 3.98 0.00 0.00 3.98 &: STAN PALMER CONSTRUCTION, INC. EXTRA WORK INITIATION FORM PROJECT: 6011 DATE: 02/16/06 X OR Z NUMBER ASSIGNED: X-I BRIEF DESCRIPTION (6 words or less): Repair water service. IF Z, BACK CHARGE FIRM: LOCATION (station, address, defined location on site): on site by existing house NOTIFICA TION: DATE AND TIME: Feb 16,06 REPORTED TO: Ned Lever HOW REPORTED: D Phone 0 Fax [ZJ In person D Other: WHO AUTHORIZED WORK TO PROCEED: Ned Lever DETAILED DESCRIPTION OF EXTRA WORK AND WHY NECESSARY: Water service was know but not marked by owner. We were asked to just dig thru it. Ned ask us afterwards to repair it. ( note the city did insure that the water was off before we hit it) FOLLOW UP WORK REMAINING: LOSS OF TIME TO CREW: ACTUAL OR ESTIMATED ESTIMA TED LOSS OF TIME TO PROJECT (work on critical path): FORSEEN IMPACTS: See daily report for more info. .. /I~I H.D. FOWLER COMPANY PON~b~~. BelleI'fELL-b6L 0 Bellevue 425.746.8400 Bellingham 360.734.8400 Bend 541.389.7577 Bremerton 360.377.4507 Clackamas 503.656.3900 Eugene 541.607.0081 Hayden 208.772.9060 Hillsboro 503.626.2466 Ship to: PO BOX 2057 BRWH # 162410 To: 11.1, .1..111 ,II, ,11111" ,11'111, I " II. , I" 11111111 I, I ,I, II, ..1 4 STA~~ PALtv1ER COi'-lSTRUCTiOi'-l 5107 STATE HIGHWAY 3 SW PORT ORCHARD WA 98367-7486 QII \/CDn^ I C VILVLI'\L.lr\L-L... Marysville Olympia Pacific Pasco Redmond Spokane Wenatchee Yakima 360.651.2400 360.459.7300 253.863-8600 509.545.0255 541.923.2090 509.568.8400 509.886.8804 509.24~8'8400 02198861 02/21/06 nter: \^/ ^ nOiJO')I"')f""\C7 v v r\ VU000L UO ( FOB: H. D. FOWLER C4\- Ship Via: WILL CALL ll.l! Qty Ship'd Qty Part # BO'd UoM Description Line DRAIN MARK PEASE EMERTON CHEM. Unit Price Extended T Price X Sub Total Freight Tax Grand Total KEVIN INOS Seruing the Pacific Northwest since 1911 3.88 0.00 0.00 3.88 Job No. 6011 ,; Job Name: Pump Station 2 Upgrades Daily Time Report Prepared By: Keith Shumaker Date: Feb 16, 06 THURSDAY III .... , VI s:: "" .!!! Q.I Q.I ..- EMPLOYEE and/or u E1U 0 No. 0 ..- ... a.... CD r SUBCONTIRACTOR 0 .- Q.I ..- >< ..c ::s a. .E'o .,-' 1Il ...J 1 2 3 4 5 6 7 8 9 10 11 12 13 14 1 2 Adrian Shippen EXC 567 8.5 3 4 5 Chuck Palmer TRK 71 3 6 LAB 5 ? - 8 Kevin Hinds PIPLAB 21 1 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 -- ~ H.D. fowler Company ~ PO BOl( 1 GO . Bellevue, Washington, 98009-01 GO Bellevue Bellingham Bremerton Clackamas Hillsboro Marysville Credit Memo C136664 To: BRWH # 162410 Ship to: PO BOX 2057 STAN PALMER CONSTRUCTION 5107 STATE HWY 3 SW 425.746.8400 360.734.8400 360.377.4507 503-656.3900 503-626.2466 360.651.2400 PORT ORCHARD (360) 674-2100 Order#: SILVERDALE W A 98367 Due: NET 10TH PROX Olympia Pacific Pasco Spokane Wenatchee Yakima 360.459.7300 253.863.8600 509.545.0255 509.568.8400 509.886.8804 509.248.8400 W A 983832057 Inv Date: Order Writer: 02/16106 DONALD SCOTT PO/JOB: FOB: Ship Via: ll.l2 - Line Qty UoM Description This credit belongs to RA: RA*BRWH*70642 WRONG MATERIAL FOR JOB 1 2 EA <11821102> FORD C66-33Q 3/4" IPS QUICK JOINT ADAPTER Sales Invoice <118211 02> 2 4 EA <11821102> 3/4" FORD IPS STIFFENER FORD #71 Sales Invoice <11821102> Serving the Pacific Northwest since 1935 Unit Price Less % Credit T Price X 9.210 -18.42 1.070 -4.28 Coo I \ - Y- \ Sub Total: CharQes: FreiQht: Tax: Grand Total: -22.70 0.00 0.00 0.00 -22.70 .~ H.D. FOWLER COMPANY PO!~O:~8e~. Bellel'iAS2or-i6b 2 To: 3 11.1111..1...11..1111111.1111.1.1..11..1..11..1'111.1.1.1111.1 STAN PALMER CONSTRUCTION 5107 STATE HIGHWAY 3 SW PORT ORCHARD WA 98367-7486 Terms: FOB: H. D. FOWLER Ship Via: llil Line Qty Ship'd Qty Part # BO'd UoM Description BRWH # 162410 Bellevue Bellingham Bend Bremerton Clackamas Eugene Hayden Hillsboro 425.746.8400 360.734.8400 541.389.7577 360.377-4507 503.656.3900 541-607.0081 208.772.9060 503.626.2466 Ship to: PO BOX 2057 o EA 3/4" FORD IPS STIFFENER FORD #71 Order#: ,. ". ~ Due:. 02196859 . 03/10/06.. W ILL CALL SiLVERDALE Inv Date: 02/16/06 2 4 kevin h inz Serving the Pacific NOl'thwest since 1911 Marysville Olympia Pacific Pasco Redmond Spokane Wenatchee Yakima 360.651.2400 360.459.7300 253-863.8600 509.545.0255 541.923.2090 509,568.8400 509.886.8804 5091918.8400 Order Writer: 'vV A 983832057 ROBERT FLOWERS Unit Price Extended T Price X 1.070 4.28 Sub Total Freight Tax Grand Total 22.70 0.00 0.00 22.70 STAN PALMER CONSTRUCTION CHANGE ORDER PROPOSAL PROJECT: ANDERSON CREEK PUMPST A TION DATE: 10/212006 TO: CITY OF BREMERTON PW 3027 OL YMPUS DRIVE BREMERTON, W A 98310 SPC CO NO: X-02 n DC' r'D TD'T'T n1\. T. .lJL>..J~_d'\_U- J.J.\Jl'l. ELECTRICAL TRENCH CONFLICTS WITH EXISTING UTILITIES REQUIRED HAND WORK AND DELAYS DIRECT COSTS FROM WORK SHEET 1 LABOR 276.16 direct labor w/fiinges safety & insurance 96.60 Direct equipment costs 0.00 Direct rental costs 0.00 Direct material costs 8.28 3% of dir~ct labor 0.00 381. 04 Prime contractor Direct Costs, small tools & supervision 0.00 Subcontractor Costs 2 EQUIPMENT OWNED 3 RENTAL EQUIPMENT 4 MATERIALS 5 SMALL TOOLS 3 % 6 DIRECT SUPERVISION 0% 7 SUB TOTAL 8 SUBCONTRACTORS 9 MARK UP ON LABOR MARKUP ON MATERIALS & SERVICES MARKUP ON EQUIPMENT 10 MARK UP ON SUBCONTRACTORS Subcontractor 29% 21% 21% 12% 80.09 0.00 20.29 0.00 11 SUBTOTAL 481.42 Total Prime and Subcontractors 12 WA State Sales tax (8.5% of Line 11) 8.60% 41.40 For calculating Bonds & Insurance amount only 13 Bonds and Insurance (1% of lines 11and 12) 1% 5.23 Bond and Insurancce on increased contract amount 14 Total Change Proposal Cost (not including WA State Tax, line 12) 486.65 Total Change Proposal STAN PALMER CONSTRUCTION CHANGE ORDER WORK SHEET PROJECT DESCRIPTION LABOR OPERATOR LABORERS-PIPELAYER & CAULKER TOTAL LABOR EQ. NO OWNEND EQUIPMENT 567 Crawler Mounted Hydraulic Excavator TOTAL OWNEND EQUIPMENT RENTED EQUIPMENT TOTAL RENTED EQUIPMENT MATERIALS TOTAL MATERIALS SUBCONTRACTORS TOTAL SUBCONTRACTORS CO NO: QNTY UNIT 3 3 3 0.00 UNIT COST 49.98 42.07 0.00 0.00 0.00 0.00 0.00 0.00 32.20 0.00 0.00 0.00 0.00 0.00 0.00 COST 149.94 126.22 0.00 0.00 0.00 0.00 0.00 0.00 276.16 96.60 0.00 0.00 0.00 0.00 0.00 0.00 96.60 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 Job No. 6011 ; ,/ Job Name: Pump Station 2 Upgrades Date: Feb 17, 06 Daily Time Report Prepared By: Keith Shumaker FRIDAY f/) .... f/) c:"C !!! C1l C1l ..- EMPLOYEE and/or 0 No. u E ca 0 N ... c.... <D I SUBCONTRACTOR 0 .- C1l '""": >< .c ~ c. ra S"o ..- ..J 1 2 3 4 5 6 7 8 9 10 11 12 13 14 1 2 3 Adrian Shippen EXC 567 4.5 3 4 5 6 Chuck Palmer LAB 5 3 7 8 9 10 11 12 . 13 14 , 15 16 17 18 19 20 21 . 22 23 24 25 26 27 28 29 . 30 S,j( STAN PALMER CONSTRUCTION, INC. EXTRA WORK INITIA TION FORM D.^..TE: 60] ] - Pump Station 2 Upgrades ]:;'p}, 17 ()~ ..I. '"'V~ ~ I, vv PROJECT: X OR Z NUMBER ASSIGNED: X-2 BRIEF DESCRIPTION (6 words or less): 12" DI pipe unmarked and unknown IF Z, BACK CHARGE FIRM: LOCATION (station, address, defined location on site): 20 ft north of existing transformer. NOTIFICATION: DATE AND TIME: Feb 17,06 REPORTED TO: Ned Lever HOW REPORTED: D Phone D Fax r:g] In person D Other: WHO AUTHORIZED WORK TO PROCEED: DETAILED DESCRIPTION OF EXTRA WORK AND WHY NECESSARY: Because of the 12" line and location ofthe existing direct bury power line ourtrench was forced even closer to the power line which ment hand work. FOLLOW UP WORK REMAINING: LOSS OF TIME TO CREW: ACTUAL OR ESTIMATED ESTIMA TED LOSS OF TIME TO PROJECT (work on critical path): FORSEEN IMPACTS: See daily report for time. STAN PALMER CONSTRUCTION CHANGE ORDER PROPOSAL PROJECT: ANDERSON CREEK PUMPST A TION DATE: TO: CITY OF BREMERTON PW 3027 OL YMPUS DRIVE BREMERTON, WA 98310 SPC CO NO: X-03 3.00 T'\ DC r<n Tn'T'T r'\lI. T. LJL0~J.'-J.r J.J.Vl'l. REMOVE CONCRETE RETAING WALL OBSTRUCTING TRENCH LINE DIRECT COSTS FROM WORK SHEET 1 LABOR 319.65 direct labor w/fringes safety & insurance 162.60 Direct equipment costs 0.00 Direct rental costs 0.00 Direct material costs 9.59 3% of direct labor 0.00 491.83 Prime contractor Direct Costs, small tools & supervision 0.00 Subcontractor Costs 2 EQUIPMENT OWNED 3 RENTAL EQUIPMENT 4 MATERIALS 5 SMALL TOOLS 3% 6 DIRECT SUPERVISION 0% 7 SUB TOTAL 8 SUBCONTRACTORS 9 MARK UP ON LABOR MARKUP ON MATERIALS & SERVICES MARKUP ON EQUIPMENT 10 MARK UP ON SUBCONTRACTORS Subcontractor 29% 21% 21% 12% 92.70 0.00 34.15 0.00 11 SUBTOTAL 618.67 Total Prime and Subcontractors 12 WA State Sales tax (8.5% of Line 11) 8.60% 53.21 For calculating Bonds & Insurance amount only 13 Bonds and Insurance (1 % of lines 11 and 12) 1% 6.72 Bond and Insurancce on increased contract amount 14 Total Change Proposal Cost (not including WA State Tax, line 12) 625.39 Total Change Proposal STAN PALMER CONSTRUCTION CHANGE ORDER WORK SHEET PROJECT DESCRIPTION LABOR POWER EQUIPMENT OPERATORS-BACKHOE, EXCAVATOR, SHOVEL (3YD & UNDER) LABORERS-PIPELA YER & CAULKER TOTAL LABOR EQ, NO OWNEND EQUIPMENT 567 Crawler Mounted Hydraulic Excavator Pick up wI jack hammer TOTAL OWNEND EQUIPMENT RENTED EQUIPMENT TOTAL RENTED EQUIPMENT MATERIALS TOTAL MATERIALS SUBCONTRACTORS TOTAL SUBCONTRACTORS CO NO: QNTY UNIT 3 4 3 3 0.00 UNIT COST 50.45 42.07 0.00 0.00 0.00 0.00 0.00 0.00 32.20 22.00 0.00 0.00 0.00 0.00 0.00 COST 151.35 168.30 0.00 0.00 0.00 0.00 0.00 0.00 319.65 96.60 66.00 0.00 0.00 0.00 0.00 0.00 162.60 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0,00 ::f- STAN PALMER CONSTRUCTION, INC. EXTRA WORK INITIA TION FORM PROJECT: 6011 - Pump Station 2 Upgrades -r;'p]-",)() ()h -L VIlJ ~'J, VV DATE: X OR Z NUMBER ASSIGNED: X-3 BRIEF DESCRIPTION (6 words or less): power/phone line and concrete wall -in trench line IF Z, BACK CHARGE FIRM: LOCATION (station, address, defined location on site): just south ofVO-l vault NOTIFICATION: DATE AND TIME: Feb 21,06 REPORTED TO: Ned Lever HOW REPORTED: 0 Phone 0 Fax ~ In person D Other: WHO AUTHORIZED WORK TO PROCEED: DETAILED DESCRIPTION OF EXTRA WORK AND WHY NECESSARY: The retaining wall continued under the existing road and had to be removed in order to get conduit thru. Hand digging need around power and phone lines coming from the existing house going to the garage. (not shown on plans.) FOLLOW UP WORK REMAINING: LOSS OF TIME TO CREW: ACTUAL OR ESTIMA TED ESTIMATED LOSS OF TIME TO PROJECT (work on critical path): FORSEEN IMPACTS: See daily report for detail time. Job No. 6011 Job Name: Pump Station 2 Upgrades Date: Feb 20, 06 MONDAY Daily Time Report Prepared By: Keith Shumaker tIJ +J tIJ c"'C ~ Q) Q) .,.... EMPLOYEE and/or u E~ (<) 0 No. ... 0.... I 0 SUBCONTRACTOR 0 .- Q) x ~ ::s 0. .0 0"0 .,.... ~ ~ W :'<'>". ~.c,.>,.......",....;.;, 1 2 3 4 5 6 ., 8 9 10 11 12 13 14 1 2 Adrian Shippen EXC 567 3 4.5 3 4 Kevin Hinds TRKOT 21 1 5 LAB 2 . 6 7 Keith Shumaker Jackhammer 3 8 9 . 10 11 12 13 14 15 16 17 18 . 19 20 21 22 23 24 25 26 27 28 29 30 Stan Palmer Construction Daily Report Job No. 6011 Job Name: Pump Station 2 Upgrades DATE: Man Feb 20, 06 WEATHER in AM: Clear and Cold WEATHER in PM: Clear and Cold WORK TODAY: Continued conduit installation. Started at VO-1 and headed up the hill. Slow start due to an existina power/phone line running parallel with trench. These iines not shown on drawing. livhen we got to the retaining wail it was found to continue under the road so we tried saw cutting it but because of the rebar a iack hammer was called for and after 3 hrs we had it out of the way. These two items were tracked as X-3. WORK DELAYS: EXTRA WORK: X-3 concrete wall removal/ power and phone line not shown on olans. MATERIALS: Pit run gravel for back fill from RV trucked bv RV 6 loads hauled during the evening (didn't get tickets as of this writing) MOB & DEMOB: STAN PALMER CONSTRUCTION CHANGE ORDER PROPOSAL PROJECT: ANDERSON CREEK PUMPSTATION DATE: 10/2/2006 TO: CITY OF BREMERTON PW 3027 OL YMPUS DRIVE BREMERTON, WA 98310 SPC CO NO: X-103 DESCRIPTION: REINSTALL PRESSURE GAUGES NOT SHOWN ON DRAWINGS DIRECT COSTS FROM WORK SHEET 1 LABOR 281.25 direct labor w/fringes safety & insurance 2 EQUiPMENT OWNED 0.00 Direct equipment costs 3 RENTAL EQUIPMENT 0.00 Direct rental costs 4 MATERIALS 82.54 Direct material costs 5 SMALL TOOLS 3% 8.44 3% of direct labor 6 DIRECT SUPERVISION 0% 0.00 7 SUB TOTAL 372.23 Prime contractor Direct Costs, small tools & supervision 8 SUBCONTRACTORS 0.00 Subcontractor Costs 9 MARK UP ON LABOR 29% 81.56 MARKUP ON MATERIALS & SERVICES 21% 17.33 MARKUP ON EQUIPMENT 21% 0.00 10 MARK UP ON SUBCONTRACTORS 12% 0.00 Subcontractor 11 SUBTOTAL 471.12 Total Prime and Subcontractors 12 WA State Sales tax (8.5% of Line 11) 8.60% 40.52 For calculating Bonds & Insurance amount only 13 Bonds and Insurance (1 % of lines 11 and 12) 1% 5.12 Bond and Insurancce on increased contract amount 14 Total Change Proposal Cost 476.24 Total Change Proposal (not including WA State Tax, line 12) ./' ./ Cv;.:::T-~.1 r-r'.:!7.'(1 :._l..'.l;,i_'l(::-r- C::~:~: 1~~25 [..lJ'!"(I ~:l:~~~l~~~ 3;:; Cl ,." ,~:i "7 (~J'" j 3 :~.; "1. EVERGREEN LUMBER Smce 1939 :~" ~.[.,~: Gr--:: h ::((-;.-.1 '; ~.J~i ':~.:-~',3r,>' SOLD TO SHiP TO :::;;- .;:-~ P(:Li\iEr~ C:U:'~f::;T", ~1 r ;::: ~"'~ :~. ("; L. /iH ~ F i _: ; ~ i"-~ ::~:: r , 5:1.0'; Sl'~1'[ j-.:S~ ~~ ;\J ':.~J.i~::7 ~:,T~~T[ !.~~r{ ~~. :-:;f,1 PD;:{T OF{~~: j(ihD,: \.d;~': ;.:.~;e:."3t~:./ ~Ol~'r (]RCj"I:~~D~ l~;~ gJ26'7 ~; h j. pmr.. ~-~ t " n: ~ ..I ~~.IM1i~ :'O~~~50 _ (-p 0 II 1;:' Hljl-I NeT Lt .-. - 'IEmB~ED _-eRMS~~~~~~;t;~ m~~_~!Ji\'l=l:il"~".~lR-i~il"I/~IiliJI/~lt.l[oj::~f.ili\1~.][oj=ll'Y:,"~~ 1;1(~373:! 0""//12/06 .~la 156')Di Ei 7 / t ~:~ / ~~.j :.:- ),:i'~ :,~,"{.~;i$;~~ -~~l;~;; ~ :}~,,~:t\ :l' ~\;~~~~;3~~~~;.r:D ES C:RlgrTI OJ~?~'~:!:~~~;~~~~~;~~f~~{~i?~i~~~~ff:?~~J~tk%i ~1.~1i~~~f.lIC~~:~'i{.,,\~? ;!~: ~ 1(, (j j t. E f) STUD (l!~C--[.!EDGE J/ 8.;< 2: 3/ :';. ;:; LJ(I.:;e.33.:i 0~ 7~5E! .L:~., ~";~;:I \ 1- ~j IJ 3 _, 'iD)oo_-, )t . \~\ \ ) .p\\- ~i~1\ // \":::----;/000- I--' X I AGREE TO THE CREDIT TERMS HEREIN 7 ./- ,,/- ,0 ///1 F / / / .//0' ..-_'_.,. >::r;;:~_____~-"---- "' J"u 1/ .. ,~. .~ .~ ~. e ~j 1.~:~ :~, 1. !J ;~ fj:3 ~ .:'1 [IT: t,.1 DRIVER MERCHANDISE 'l';':~ 'R- '~f ~, :;,-, <. ;~ :!l~' ; f :.r:. t:- x :J: ~.:~ ,'.~' SHIP VIA OTHER ,!.:,:::, l~ I !!'/D T CE i~' (\i:':::: !..:i.. r:.~ "'.1'1',-, .::; TAX : ~ ~.~ ';E- .;:t. .:/ ~f j:- ..<. A. }f: ~.: .\.::. '-;.~. .Y".i ,~ ~.'. ) ,-;" " j }': q ,/ ;3n i'(1 ;,'j ,.:' ,-. H ':~: Cl ""'. '~:.;~ ;'~ ;") ":', -.. ~.. -(.:i ::' ~ [; f1.:.~. HI -- :.':i ;~ ~1 ~;} ;".; r(! . :~..~'t .~~. {\; :~;:.~')-:7i [\;~.. ;'.::'.1 c: ;., C 1. '~~l~~l::d ~)l_~ rId ,~':_ .'f FREIGHT ; '.."~ T()TAL CUSTOMER INVOICE ~/. .. n FERGUSON ~, ENTERPRISES,INC~ 1012 132nd STREET SOUTHWEST EVERETT, WA 98204-7328 1~::;;;:4NVMI3(;Fl:i6U9~~()MEFlI>;t(GE:1 Please contact with Questions: PLEASE REFER TO INVOICE NUMBER WHEN MAKING PAYMENT AND REMIT TO: ~ FERGUSON ENTERPRISES, INC: 425-742-4748 FEI - EVERETT #3023 PO BOX 802806 CHICAGO, IL 60680-2806 111111111111.111.11..1'1.11...111..11..1..11..111..1'1.1.1.1.1 STAN PALMER CONSTRUCTION 5107 STATE HWY 3 SW PORT ORCHARD, WA 98367-7486 rJ I....> ........><..>.~HirjQi>................. ........................./...............<.>.....j 00004938 21 4938 vu' \ ?~/7 COUNTER PICK UP 1441 LUMSDEN ROAD PORT ORCHARD, WA 98367-9801 SHIP SELL TAX CODE CUSTOMER ORDER NUMBER SALESMAN WHSE. WHSE. JOB NAME INVOICE DATE BATCH 3009 3009 WAE 6011 PBPl;HI:;P .($H~pgl;Q .. ...)'.:)]!?MNWMQ!:;:ft.'.:>> 023 X103 10 07/13/06 36236 f(JJ!~JmJ?:~~:!qg} \tJJMi If \~:~~i((~tl~MJ~~:Y~]{:r~~::~:)r 1 1 10 10 1 BRNDK 1 RTC 10 B606 10 B616 1/2X2 BRS NIP 3/8 00 SOFT REF TUBE 3/8 00 COMP SLV 3/8 COMP NUT 2.463 EA 62 .412 EA 0.260 EA 0.299 EA 2.46 62.41 2.60 2.99 INVOICE SUB-TOTAL 70.46 . " "':1 :1 -1/1/ -c. 1 7 .~~~~~ are due an}p~ableO;W tlfe~R~iced terms. All past due amounts are subject toO"Rle?Jco/},~art~YP.tf~aXimUrn rate allowed>t9t~SB9~r 70.46 state law plus costs at collection including attorney lees if incurred. Freight terms are FOB our dock unless otherwise specified above. WARRANTY PROVISiONS. SEE REVERSE SIDE A A ,,, ^'- FERGUSON ." ENTERPRISES, INC~ 1012 132nd STREET SOUTHWEST EVERETT, WA 98204-7328 ~::;;~~~NlJJ\III3E:R<~:9~'T6QMgFf !<;AGE>I Please contact with Questions: PLEASE REFER TO INVOICE NUMBER WHEN MAKING PAYMENT AND REMIT TO: fi$ FERGUSON ENTERPRISESj INC: 425-742-4748 STAN PALMER CONSTRUCTION 5107 STATE HWY 3 SW PORT ORCHARD, WA 98367-7486 ~ { 0_'3 {;D tI i FEI - EVERETT #3023 PO BOX 802806 CHICAGO, IL 60680-2806 !':$HII?TQi::1 COUNTER PICK UP 1441 LUMSDEN ROAD PORT ORCHARD, WA 98367-9801 SHIP SELL TAX CODE CUSTOMER ORDER NUMBER SALESMAN NHSE, WHSE, JOB NAME INVOICE DATE BATCH 3009 3009 WA3009 6011/TAXABLE :!:BQl;Bgp ) $.I:Ime~Pt) :;::)tl]l?MNYMEigF{::) 023 X103 IO 07/13/06 36236 ,PNrrPRlpg:\;::VM?t ::AMQl.JN1\<:' R31622 R44852 1/8"- 1-1/8 ENCL FEED CTTR 150 1/4 5/16 3/8 TUBE BENDER 456 INVOICE SUB-TOTAL TAX WA-B 3009 PT 0 HARD 25.990 EA 36.051 EA 25.99 36.05 62.04 5.34 l; L s\~ ~~\ cJ RMS: NET 10TH PROX ORIGINAl INVpTCE 67.38 ccounts are due ana payable per Hie Invoiced terms. All past due amounts are subject to a servIce cnarge a toe maximum rate allowed ,ate law plus costs of collection including attorney fees if incurred. Freight terms are FOB our dock unless otherwise specified above. WARRANTY PROVISIONS, SEE REVERSE SIDE A A +--------------------------------------------------------------------------+ tPress Esc Key to Insert new record, Ctrl-Z to Clear form ,. tPress Del Key to Terminate Insert Mode t t INSERT Contract Maintenance t ~ Contract Number 4544 ~ tVendor Name STAN PALMER CONSTRUCTION INC t tSubject ANDERSON CREEK WELLFIELD IMPROVEMENTS t tDepartment ENGINEERING t tStatus Code CON t ,. Amount $459921.00 t ,. Begin Date 01/18/2006 t t Insurance End Date 07/31/2006 ,. t Type Amount Review Date 07/01/2006 t t Press Fl for GL $2000000.00 t t valid insuranceAL $1000000.00 t T type codes T t Insurance Total $3000000.00 t t Insurance Review Date 07/01/2006 t ~ Comments PUMP STATION 2 UPGRADES ~ t t t ,. +--------------------------------------------------------------------------+ . . . . I I I I I I I II I I I I I' I I SECTION 00500 - AGREEMENT THIS AGREEMENT is dated the 1 Y+-h day of j(l.VlIUl.Ytj-- in the year 20 ao by and between City of Bremerton (hereinafter called CITY) and STAN PALMER CONSTRUCTION. INC. (hereinafter called CONTRACTOR). CITY and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: ARTICLE 1. WORK. CONTRACTOR shall complete the WORK as specified or indicated in the CITY's Contract Documents entitled Anderson Creek Wellfield Improvements, Pump Station No.2 Upgrade ARTICLE 2. CONTRACT TIMES. The WORK shall be completed, to Substantial Completion within 150 Calendar Days after the CITY issues Notice to Proceed, and to Final Completion within 180 Calendar Days after the CITY issues Notice to Proceed. ARTICLE 3. LIQUIDATED DAMAGES. CITY and the CONTRACTOR recognize that time is of the essence of this Agreement and that the CITY will suffer financial loss if the WORK is not completed within the times and Phases specified in Article 2 herein, plus any extensions thereof allowed in accordance with the General Conditions & Supplementary Conditions. The CITY and the CONTRACTOR also recognize the delays, expense, and difficulties involved in proving in a legal proceeding the actual loss suffered by the CITY if the WORK is not completed on time. Accordingly, instead of requiring any such proof, the CONTRACTOR shall pay the CITY $1,000 as liquidated damages for each day that expires after the dates or times specified in Article 2 herein for Substantial Completion and Final Completion of the' WORK in accordance with the General Conditions and Supplementary Conditions. ARTICLE 4. CONTRACT PRICE. CITY shall pay CONTRACTOR for completion of the WORK in accordance with the Contract Documents in the amount set forth in the Bid Proposal, which shall include sales tax as provided in Section 00100 of the Specifications. ARTICLE 5. PAYMENT PROCEDURES. CONTRACTOR shall submit Applications for Payment in accordance with the General Conditions & Supplementary Conditions. Applications for Payment will be processed by the OWNER as provided therein. co~ City of Bremerton Anderson Creek Wellfield Improvements Pump Station No.2 Upgrade AGREEMENT PAGE 00500 - 1 ARTICLE 6. CONTRACT DOCUMENTS. The Contract Documents which comprise the entire agreement between CITY and CONTRACTOR concerning the WORK consist of this Contract (pages Contract-1 to Contract-3, inclusive) and the following attachments to this Contract: o Notice Inviting Bids, o Bidders Checklist, o Bid Proposal including the Proposal Forms, Information Required of Bidder, Bid Bond, and all required certificates and affidavits, / 0 Performance Bond, 0 Payment Bond, 0 General Conditiol'Js, 0 Supplementary Conditions, 0 Contract Specifications, 0 Contract Drawings, o . Addenda numbers to ---2-, inclusive. o Change Orders which may be delivered or issued after Effective Date of the Agreement and are not attached hereto. There are no Contract Documents other than those listed in this Article 6. The Contract Documents may only be amended by Change Order as provided in the General Conditions & Supplementary Conditions. ARTICLE 7. INDEMNIFICATION. The CONTRACTOR and CITY acknowledge and agree that they have negotiated the following in accordance with the requirements of RCW 4.24.115 and the CONTRACTOR specifically waives his immunity under industrial insurance under Title 51 RCW. To the fullest extent permitted by Laws and Regulations, the CONTRACTOR shall indemnify, defend, and hold harmless the CITY, ENGINEER, and DESIGN ENGINEER, their consultants, subconsultants, and the officers, directors, employees, and agents of each and any of them, against and from any and all claims, injuries, damages, losses or suits, including all legal costs and attorney fees, all claims and liability arising under, by reason of, related, or incidental to the Contract Documents or any performance of the WORK, but not from the sole negligence or willful misconduct of the CITY and/or the ENGINEER as further defined in the Contract Documents. The provisions of this section shall survive the termination of the contract. See the Supplementary Conditions for additional indemnification requirements. ~ Contractor Initials City of Bremerton Anderson Creek Wellfteld Improvements Pump Station No.2 Upgrade AGREEMENT PAGE 00500 - 2 I I I I I I I 'I I I I I I I I I I I I I I I I I I I I I I I I I I I I , I I ARTICLE 8. ASSIGNMENT No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and specifically but without limitation monies that may become due and monies that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. The CITY, in its sole discretion, may refuse to allow the CONTRACTOR to assign any or all of its duties, rights and/or responsibilities under the Agreement, except with regards to an assignment of funds for security purposes. In the case of an assignment for security purposes the CITY may condition its approval to the extent it deems necessary to assure that there will be adequate funds to complete the WORK and to pay a subcontractors and suppliers. CITY and CONTRACTOR each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect of all covenants, agreements and obligations contained in the Contract Documents. CI IN WITNESS WHEREOF, the day and year first ab and CONTRACTOR have caused this Agreement to be executed ritten. By PALMER CONSTRUCITPN, INC. Attest Address for giving notices 3"'5 &i~4-h Sf- s\Ja~ 1,,00 6V'e.l'Y\e.-y-ro~ wA (\833; -l~' 3 Address for giving notices 5107 STATE HWY 3 SW, PORT ORCHAR, WA. 98367 License No. ST-AN-PC-*202NF Agent for service of process: (Signature) (Title) /- City of Bremerton Anderson Creek Wellfield Improvements Pump Station No.2 Upgrade AGREEMENT PAGE 00500 - 3